Document of The World Bank FILE COPY FOR OFFICIAL USE ONLY Report No. P-3132-IND REPORT AND RECOMMMENDATION OF THE PRESIDENT OF THE INTERNATIONAL BANK FOR RECONSTRUCTION AND DEVELOPMENT TO THE EXECUTIVE DIRECTORS ON A PROPOSED LOAN TO THE REPUBLIC OF INDONESIA FOR AN ELEVENTH POWER PROJECT October 22, 1981 This document has a restricted distribution and may be used by recipients only in the performance of their official duties. Its contents may not otherwise be disclosed without World Bank authorization. CURRENCY EQUIVALENTS Currency Unit - Indonesian Rupiah US$1 = Rp 625 Rp 100 = US$0.16 Rp 1 million US$1,600 WEIGHTS AND MIEASURES 1 metric ton = 1,000 kilograms (kg) 1 liter (1) = 0.0063 barrels 1 kilometer (km) 0.6215 miles (mi) 1 kilovolt (kV) = 1,000 volts (V) 1 megavolt-ampere = 1,000 kilovolt-amperes (kVA) 1 kilovolt-ampere 1,000 volt-ampere (VA) 1 megawatt (1W) = 1,000 kilowatts (kW) 1 gigawatt hour (GWh) 1 million kilowatt hours (kWh) ABBREVIATIONS BAPPENAS - National Planning Agency BATUBARA - National Coal Entity DGEP - Directorate-General Electric Power, Ministry of Mines and Energy DKI - Daerah Khusus Ibukota, the special district of the capital city of Jakarta GOI - Government of Indonesia LNG - Liquified natural gas MME - Ministry of Mines and Energy ODA - Official Development Assistance PCR - Preece, Cardew and Rider, UK PERTAMINA - National Oil Company PLN - National Power Authority REPELITA - Five-Year Development Plan PLN'S FISCAL YEAR April 1 - March 31 GOVERNMENT OF INDONESIA FISCAL YEAR April 1 - tarch 31 FOR OFFICIAL USE ONLY INDONESIA ELEVENTH POWER PROJECT LOAN AND PROJECT SUMMARY Borrower: Republic of Indonesia Beneficiary: Perusahaan Umum Listrik Negara (PLN), the national electricity authority Amount: $170 million equivalent Terms: 20 years, including 5 years of grace, with interest at 11.6% per annum. Onlending Terms: The proceeds of the loan will be onlent from the Govern- ment to PLN on the same terms as the Bank loan; the Government will bear the foreign exchange risk. Project Description: The main objectives of the project are to increase PLN's transmission and distribution capacities, enable grid extensions to be made to rural areas, and provide consul- tancy services for schemes which will enhance the use of coal, develop an effective grid system and continue PLN's institutional growth. The project will consist of: (a) a distribution system for Jakarta and the regencies of Bogor, Tangerang and Bekasi (Jabotabek) in West Java involving construction of about 450 km of 20 kV cables, 760 km of 20 kV overhead lines, 1,336 sub-stations and 800 pole-mounted transformers, about 5,300 km of new low voltage lines and some 320,000 service connections; (b) a high-voltage (HV) system, complimentary to (a) above, involving five new sub-stations in Jakarta, 46 km of double- circuit 150 kV cables and 980 MVA of transformers; (c) engineering of the next base-load coal or multiple-fired thermal power units in Java; (d) engineering of the Extra High Voltage (EHV) Central-East Java transmission line; and (e) management consultancy for further improvements in PLN's financial planning and control systems. This document has a restricted distribution and may be used by recipients only in the performance of their official duties. Its contents may not otherwise be disclosed without World Bank authorization. - ii - There are no unusual risks associated with this transmission and distribution project. Estimated Costs: Local Foreign Total ----- ($ million) ----- Base Costs Jabotabek distribution 61.5 99.4 161.0 Jabotabek high voltage system 24.2 64.8 89.0 Engineering of new thermal power units in Java 0.5 3.7 4.2 Engineering of Central-East Java EHV Extension 0.2 0.8 1.0 Management consultancy 0.2 0.6 0.8 Subtotal 86.6 169.3 256.0 Contingencies Physical 4.3 8.2 12.5 Price 22.5 28.5 50.9 Total Costs 113.4 206.0 319.4 Financing Plan: Local Foreign Total …($ million) ---- Source IBRD - 170.0 170.0 PLN/Government 113.4 36.0 149.4 Total 113.4 206.0 319.4 Estimated Bank FY 1982 1983 1984 1985 Disbursements: Annual 5.0 28.0 110.0 27.0 Cumulative 5.0 33.0 143.0 170.0 Rate of Return: 18%. Staff Appraisal Report: No. 3468-IND, dated September 30, 1981. REPORT AND RECOMMENDATION OF THE PRESIDENT OF THE INTERNATIONAL BANK FOR RECONSTRUCTION AND DEVELOPMENT TO THE EXECUTIVE DIRECTORS ON A PROPOSED LOAN TO THE REPUBLIC OF INDONESIA FOR AN ELEVENTH POWER PROJECT 1. I submit the following report and recommendation on a proposed loan to the Republic of Indonesia for the equivalent of $170 million to help finance an Eleventh Power Project. The loan would have a term of 20 years, including five years of grace, with interest at 11.6% per annum. The proceeds of the loan would be onlent to Perusahaan Umum Listrik Negara (PLN), the national electricity authority, on the same terms as those of the proposed loan. The foreign exchange risk will be borne by the Government. PART I - THE ECONOMY 2. A basic economic report, "Indonesia: Growth Patterns, Social Progress and Development Prospects" (No. 2093-IND dated February 20, 1979), was distributed to the Executive Directors on February 26, 1979. An updating country economic memorandum, "Indonesia: Long-Run Development and Short-Run Adjustment" (No. 2788-IND, dated February 20, 1980), was distributed to the Executive Directors in 1980 and a further country economic memorandum, "Indonesia: Development Prospects and Policy Options," (No. 3307-IND dated April 6, 1981) was distributed to the Executive Directors on April 13, 1981. Annex I gives selected social and economic indicators for the country. Background 3. The Republic of Indonesia is an archipelago of more than 13,000 islands covering a land area of about two million sq km. With over 145 million people /1 it is the world's fifth most populous nation. The popula- tion density exceeds 650 persons per sq km on Java, where 62% of the population live, but averages less than 30 persons per sq km in the rest of the country; over 80% of the population live in rural areas. GNP per capita is estimated to be $430./2 4. The economy has grown at an annual rate of almost 8% for over a decade - the highest sustained growth rate of any low-income country. Until about the end of the First Five-Year Development Plan, Repelita I (1969/70 to /1 Preliminary results of the 1980 population census. /2 Estimate for 1980. - 2 - 1973/74), this rapid growth was largely due to effective recovery from the severe dislocations of the 1960s. The Government of Indonesia (GOI) took effective action to restore and then maintain macroeconomic stability, liberalize the economy and provide incentives for investment. There was a major rehabilitation of the neglected infrastructure, and the investment rate doubled to 18% of GDP. Since then growth has been greatly assisted by international developments, in particular the dramatic increase in oil prices and the commodity boom. Net oil exports increased from $0.6 million in 1973/74 to over $10 billion in 1980/81 and as a result the balance of payments moved into current account surplus - of $2 billion in 1979/80 and almost $3 billion in 1980/81 - for the first time in over two decades. Although production linkages with other sectors have been very weak, the oil enclave has had an important influence on overall growth through the infusion of foreign exchange resources into the economy. Growth has been well diversi- fied, with sectoral growth rates varying from 4% per annum in agriculture to 12% per annum in manufacturing and construction. However, despite the favorable growth performance, the economy is still underdeveloped, with a share of manufacturing in GDP of less than 10%, and a persistent deficit on the nonoil current account. Present projections of supply and demand for oil suggest a decline in net export revenues of the oil sector in relation to the growing needs of the economy, in the second half of the decade. For viable long-run growth the economy will have to undergo significant structural changes during the 1980s, to effect a broad-based expansion of industrial production and of both industrial and agricultural exports. Incomes and Poverty 5. Average incomes per capita have been growing at 5% per annum, but Indonesia remains an extremely poor country. It is estimated that almost 50% of the population, some 65 million persons, were living in conditions of absolute poverty in 1978. Household expenditure surveys indicate some reduction in poverty incidence in the 1970s, especially in urban areas, but a widening in rural urban disparities. The core of the poverty problem continues to be in rural Java, where landless laborers form a large proportion of the population. Here the number in poverty appears to have increased to around 50 million by the end of the decade. 6. The availability of productive employment is a key determinant of incomes. Total employment has been increasing at 3.3% p.a. during the 1970s. In 1977/78 open unemployment was less than 2% in rural areas and about 6% in urban areas. There was, however, a particularly heavy incidence among young educated males - 30% for urban males aged 20-24 with secondary school educa- tion. In the period 1971-78, manufacturing provided only 6% of the increase in employment, and mining almost none, while the more labor-intensive agricul- ture and tertiary sectors provided 42% and 52% respectively. Agriculture still accounted for 61% of total employment at the end of the period. Because the oil sector has played a leading role in economic growth, thereby - 3 - encouraging a fast growing tertiary sector, the relative lack of industrial employment has not had serious consequences in the past. However, in the future, the growth of the industrial sector will be of critical importance for the direct and indirect provision of employment. It is also clear that increasing remunerative employment in agriculture, for example in cash crop production, will have a major role to play in poverty alleviation. 7. Significant progress has been made in the social sectors. Universal primary enrollment will be achieved in the near future, and an adult literacy rate of 62% compares well with an average of 50% for other low-income coun- tries. However, secondary and higher education is comparatively less well developed, and this has been a major factor behind the current shortage of skilled manpower. With respect to health and demographic indicators, there have been significant declines in both crude birth and death rates. An effec- tive family planning program helped reduce fertility rates on Java and Bali, while the 46% reduction in the crude death rate between 1960 and 1979 was only exceeded by seven developing countries. However, the level of provision of services remains underdeveloped, and only 12% of the population has access to safe water, compared with 29% for all low-income countries. Policy for Structural Adjustment 8. Indonesia's past growth performance has been good, but the country is now faced with the need both to put the non-oil economy on to a viable long-run growth path and to effectively improve the basic needs situation of the poor. The three primary goals of the Third Five-Year Development Plan, Repelita III (1979/80 to 1983/84), are equity, growth and the maintenance of national stability. The fact that Indonesia's resource position is likely to be favorable for the first half of the 1980s presents the country with an unusual opportunity to take effective policy action to bring about the adjustments required to realize these goals. 9. Although the main concern for the allocation of the resource wind- fall is with long-run development, the maintenance of short-run stability is also important. The channeling of the foreign exchange resource into the economy, not least via the GOI budget, is already putting pressure on domestic markets and encouraging a rapid expansion of liquidity. There is a risk that medium-term supply responses will be too slow to prevent an acceleration of inflation and an erosion of international competitiveness. This emphasizes the importance of a distribution of incremental expenditure in favor of improving sectoral supply responses. In particular, it is important that a reasonable expansion of credit to the private sector be maintained - in the past this has been excessively squeezed to maintain monetary stability. This could entail a slower rate of expansion of GOI expenditure. - 4 - 10. The performance of the industrial sector will be of critical impor- tance to long-run development. GOI is planning a program of largescale industrial investments, in refineries, LNG, petrochemicals, fertilizer, cement, pulp and paper, basic metals and mining, with an estimated investment cost of $15-20 billion. This will broaden the industrial base, but will have very limited employment implications. Of greater importance for employment is the encouragement of small- and medium-scale private manufacturing. The 1978 devaluation from Rp 415 to Rp 625 per US dollar significantly improved the profitability of labor-intensive import substitution and export industries and was accompanied by a system of export certificates (tax rebates) to provide additional incentives. The trade regime is still characterized by a wide variation in rates of effective protection, but GOI is taking measures to rationalize the system. However, the private sector also suffers from a heavy regulatory burden, especially in the area of investment licensing, and limitations on the availability of credit. These will require further policy reforms to create an environment conducive to private investment. 11. Despite the abundance of energy resources, Indonesia faces a potentially serious long-run energy problem. Oil and gas now account for 98% of domestic consumption of commercial energy and demand has been growing rapidly. If Indonesia is to avoid a serious reduction in foreign exchange from the oil sector in the 1990s, it is essential to diversify energy usage, in particular through the development of the coal, hydropower and geothermal potential. This will require both a major investment program in this decade and measures to encourage interfuel substitution and more efficient energy use. The most important policy measure required is the gradual elimination of the subsidy on some petroleum products that is now a major distortion in the system. 12. Agriculture will continue to be of great importance for export reve- nue (agriculture accounted for 75% of 1979 non-oil export revenue), food pro- duction and employment. Rice production has been steadily rising to a record level of around 20 million tons in 1980, compared with 13 million a decade earlier, largely as a result of irrigation and the dissemination of new agri- cultural technology. Future investment in physical infrastructure, especially irrigation and roads, combined with a favorable market environment will be the main determinants of further expansion in food production. Tree crops have suffered from relative neglect, and the age structure of the trees is now very old, but GOI has a highly ambitious program of rehabilitation and replanting. This will require substantial investment in manpower and improved organization of distribution and marketing. 13. To sustain rapid economic growth and reduce poverty, substantial investment in human resources development will be critical. The lack of skilled manpower affects almost every sector. Shortages are largely due to the poorly developed secondary and higher education system, although the high rates of unemployment amongst secondary school leavers suggest a major - 5 - mismatch between supply and demand at this level. In the short run there is scope for better utilization of existing manpower through stopgap training schemes, while available foreign exchange resources could be used to finance fellowships abroad and, in the interim, to purchase foreign skills. There is also a strong justification for the use of incremental resources in the health sector. However, increased outlays on health infrastructure and urban and rural water supply will have to be complemented by the development of innovative approaches to identifying and tackling health problems, involving the participation of local communities. The successful family planning program provides a good model. 14. The public sector has been of growing importance, with central government expenditures now accounting for around 30% of GDP. A significant fraction of incremental resources, about 50% in 1980/81, has gone directly to public and private consumption in the form of higher civil service and military salaries from initial low levels, and subsidies on commodities. Subsidies on petroleum products, food and fertilizer have grown very rapidly to a budgeted level of over $3 billion in 1981/82. Although this has shielded the economy from sudden shocks, the long-run impact on inflation is likely to be limited and consumption data suggest that the main beneficiaries have not been the very poor. Resources for development have also risen rapidly, to the extent that it now appears that the financial constraint is often less important than nonfinancial constraints, including the availability of skilled manpower, the capacity of the construction industry and limited administrative capability. The administrative framework for project implementation was greatly improved in 1979 by the introduction of simplified appropriation procedures and the adoption of post-auditing practices. However, restrictions in eligibility of certain smaller contracts to small firms controlled by economically weak groups is likely to delay local project implementation. Wider issues of administration, including the question of decentralization, are also under review. Finally, there is a continuing need to increase allocations to maintenance of public investments, notably in irrigation and roads. Domestic Resource Mobilization and External Capital Flows 15. The external resource surplus has greatly helped GOI's budgetary position. However, in order to reduce the dependence on oil revenue and lay the foundation for long-term resource mobilization it is important to maintain the domestic effort. Domestic revenue is of particular value since expendi- ture from this source has a smaller inflationary impact than expenditure from oil revenue. Non-oil tax revenue as a proportion of nonmining GDP actually declined from almost 10% in 1978/79 to less than 9% in 1979/80 and 1980/81. It is important that the capacity of the tax system be increased through expanding the tax base, eliminating loopholes, and improving administration. There is also great scope for mobilization of resources through reduction of the subsidies on petroleum and other products. A steady rise in domestic petroleum prices to the international level during the 1980s would have a major impact on budget savings. - 6 - 16. External financing of GOI expenditure is budgeted at $2.4 billion in 1980/81 or 20% of the development budget, compared with almost 40% in 1978/79. Total disbursed and outstanding external public debt was about $15 billion at the end of 1980; including undisbursed amounts, external public debt totalled almost $24 billion. The Inter-Governmental Group on Indonesia (IGGI) remains the principal source of external capital, including Official Development Assistance (ODA), to the country. New commitments in 1980 were almost equal to the $2.1 billion recommended in the Bank's 1980 economic memorandum on Indonesia. Public sector commercial borrowings are estimated to have reached $1.7 billion in 1980. With the increased availability of foreign exchange, in the near term capital inflows are not required on resource grounds. However, during the disbursement periods of projects currently being considered, a resource gap will re-emerge in Indonesia. In addition, there is still an urgent need for support of policy and institutional changes embodied in foreign loans. It is anticipated that ODA will continue at a reduced real level, and on harder terms, in the first half of the 1980s. It is of particular importance that external finance be used to support policies designed to prevent the re-emergence of a serious resource deficit toward the end of the decade. It is anticipated that the public debt service ratio, with oil exports on a net basis, will remain in the region of 9-10% for the first half of the 1980s. 17. In the past, selective local cost financing of projects has been recommended on the grounds that finance of only the foreign exchange cost of projects would not suffice to meet Indonesia's capital requirements. In view of the present favorable resource position, in the future local cost financing will be limited to projects of key importance and where such financing is required to ensure a significant Bank contribution. PART II - BANK GROUP OPERATIONS IN INDONESIA 18. As of September 30, 1981, Indonesia had received 48 IDA credits totalling $931.8 million, and 59 Bank loans amounting to $3,814.0 million. IFC investments totalled $132.5 million. The share of the Bank Group in Indonesia's total (disbursed) external debt outstanding at the end of 1979 was about 9.5%, and the share of debt service about 4.7%. By the end of 1980, these ratios are estimated to have increased to around 10.8% and 6.7%, respectively. Annex II contains a summary of IDA credits, Bank loans and IFC investments as of July 31, 1981, as well as notes on the execution of ongoing projects. Given the critical importance of agriculture (including transmi- gration) for employment, food security and exports, over one-third of Bank Group supported projects have been in this sector. In addition, loans and credits have been extended to virtually all other sectors of the economy, including transportation, education, urban development, water supply, rural development, nutrition, industrial development financing (including small-scale industry), power, telecommunications, population and technical assistance. - 7 - 19. During Repelitas I and II, and in line with the objectives of these first two Five-Year Plans, a high proportion of Bank Group lending was directed initially toward the rehabilitation and then the expansion of infrastructure and production facilities. Special attention was also given to meet the shortage of skilled manpower and technical assistance needed for preinvestment studies and project execution. Repelita III, published in early 1979, stressed the need for continued high growth and stability, but departed from previous plans by placing special emphasis on more equitable income distribution and poverty alleviation. This focus, which was fully in line with the conclusions of the basic economic report, required greater attention to employment generation (particularly in the industrial sector) and to improvements in basic public services. While Bank lending was already consistent with these objectives, increased emphasis is being given to GOI's new priorities. 20. The resource surplus discussed in Part I of this report provides GOI with a unique opportunity to accelerate its development effort. This will require both effective policy reform, notably in improving the policy environment for private investment, and major investments in industry, infra- structure, treecrop development and human resources development. The Bank's program of lending and economic work is being geared to support the required measures. Since the resource constraint has been alleviated, at least temporarily, the primary emphasis of Bank involvement will be on policy and institutional development and technical assistance in the key sectors. This will involve a close integration between sector work. and lending and the gradual broadening of lending to the subsector and sector level in order to assist with policy issues at this level. 21. The only significant shift in the composition of lending involves a rapid expansion planned in the education sector, a direct response to the severe shortage of skilled manpower. In the industrial sector, in-depth sector work focused on a policy for the promotion of labor-intensive export- oriented growth, and it is planned to follow this with a series of industrial projects. In energy, new sector work and continued lending will concentrate on policies to diversify Indonesia's energy base, rationalize pricing and improve sectoral planning. Irrigation and treecrops will continue to absorb a substantial portion of lending in view of the importance of these sectors, and continued support for transport is anticipated. Increased lending is planned in the areas of provision of social services, in population, health and nutrition, urban development and water supply. In these areas there will be increased emphasis on institutional support and the develpoment of innovative low-cost solutions. For example, the proposed health project will focus on improving the working of the whole health care system at the level of a specific province. - 8 - 22. For about the last two years the Bank and GOI have made a major effort to improve disbursement performance. Many of the problems appear to be related to GOI's cumbersome budgetary, procurement and payment procedures, including issuance of tender documents and opening of letters of credit. These problems are further compounded by the severe shortages of both managerial and technical manpower. A number of steps have been taken by GOI and the Bank to address these issues. Several special Bank missions have visited Indonesia to analyze the problems and make recommendations for simplifying budgetary and financial procedures. The GOI and the Bank have also instituted formal and regular joint review procedures to identify general and project-specific problems and work out corrective measures. The first of these reviews was held in June 1979 and a second, more comprehensive one, in September 1980. In addition, a procurement seminar was held in Jakarta in September 1979. As a consequence of these joint initiatives, GOI has taken several measures to streamline some of the complex budgetary and financial procedures affecting project implementation. Finally, to reduce initial project implementation difficulties, many operations are now being presented for Board consideration at a later stage in the project cycle. Indications are that, as a result of these efforts, improvements are taking place. This was reflected in an increase in disbursements from $204.0 million in FY79 to $277.8 million in FY80, and to $373.5 in FY81. While it is important that the Bank and GOI maintain their efforts, these trends are encouraging. 23. From 1968 until 1974, all lending to Indonesia was made through IDA. Due to the country's improved creditworthiness following the commodity and oil price boom in 1973/74, the bulk of the Bank Group's subsequent lending has been through IBRD loans, with a modest amount of IDA lending being justified primarily on poverty grounds, as the per capita GNP was well below the IDA -.utoff of $625. Given Indonesia's much improved balance of payments position, IDA lending was discontinued in FY80. 24. The proposed project constitutes the second lending operation pre- sented to the Executive Directors this fiscal year. The Jakarta Cikampek highway has been previously approved this fiscal year and projects under advanced stage of preparation and appraisal include the Bukit Asam mining and transport, second seeds, tenth education and second fertilizer distribution projects. PART III - THE ENERGY SECTOR AND ELECTRICITY SUBSECTOR Energy Resources 25. Indonesia is richly endowed with energy resources including oil, natural gas, coal, hydropower and geothermal energy. Petroleum reserves have been exploited for some time, and petroleum now accounts for 90% of total commercial energy consumption. Reserves are estimated at about 50 bil- lion barrels, but proven resources are between 10-15 billion barrels. With - 9 - production at around 1.6 million barrels per day, projected increases in domestic demand could rapidly reduce the surplus available for export and have serious consequences for the growth of the economy. GOI has therefore adopted a policy of promoting alternative indigenous energy sources for domestic consumption such as coal, natural gas, hydroelectricity, and geo- thermal. 26. Indonesia-s coal reserves are conservatively estimated at 1.2 bil- lion tons, 86% of which are in Sumatra and the balance in Kalimantan. Some estimates place the total reserves at as high as 15.0 billion tons: explora- tion to prove the extent of reserves is proceeding only slowly. Production is currently running at about 300,000 tons per year. Consistent with GOI policy of increasing the utilization of nonoil energy resources, coal production is now to be expanded. To this end, a major project is being developed at the Bukit Asam field in South Sumatra. This project, which is being considered for Bank financing, would involve production of 3 million tons per year by 1987; most of its output will be used for power generation at the Suralaya thermal station in West Java. In addition, foreign private sector participation is being actively solicited for the exploitation of Kalimantan fields. 27. The estimated natural gas reserve is about 70 trillion cu ft, of which 5 trillion cu ft represents gas associated with oil production. The present production level is about 800 billion cu ft per year, nearly half of which is exported to Japan in liquified form. Pipelines have recently been laid to steel and fertilizer factories and domestic consumption is expected to increase at the rate of 15% per year during the next ten years. 28. The theoretical hydropower potential of the country has been roughly estimated at 31,000 MW. Although the distribution is not ideal (the greatest potential lying in Irian Jaya where electricity demand is smallest, while Java has the greatest demand and least potential), exploitation of this potential to the extent possible is also a central element of GOI energy policy. In FY81 the Bank loaned $250 million to support a major hydroelectric project at Saguling in Central Java (Loan 1950); other hydro- electric projects are under construction in Sumatra and at the planning stage in West and Central Java. 29. While geothermal resources are known to exist in a number of observed fields, stretching from Sumatra to Irian Jaya, the exact extent is not yet known. Development is so far confined to a 30 MW first stage project at Kamojang, Java, but contracts have recently been initialed for the formation of a joint venture with the Union Oil Company to exploit another Java field to 300 MW by 1986. 30. Besides promoting the exploitation of alternative commercial energy sources, GOI is also exploring the possibility of substituting charcoal for kerosene, which is widely used for cooking, and in rural areas also for - 10 - lighting. Indonesia's forestry resources are abundant, and since they represent renewable sources of energy, the country could derive considerable savings if appropriate technologies were developed to facilitate the use of firewood for energy. A USAID-funded study is shortly to be launched to shed more light on these and related renewable energy options. Energy Policy 31. The principal agency responsible for the implementation of GOI policies in the energy sector is the Ministry of Mines and Energy (MME). MME was established in 1978 to coordinate all activities in the energy sector and control the state enterprises responsible for the execution of GOI policies in the energy subsectors - oil and gas (PERTAMINA), coal (BATUBARA) and electricity (PLN). Other ministries and agencies are also involved in the sector; for example, Public Works supervises hydropower sources, Agriculture oversees forestry products, and the National Atomic Energy Commission is responsible for nuclear development. In order to ensure appropriate coordination of energy policy the President recently established an inter-ministerial National Energy Board to oversee sectoral development. 32. The general sector objectives expressed in Repelita III may be summarized as follows: (a) diversification of primary energy sources, with particular emphasis on renewable sources; (b) improving the efficiency of energy conversion and utilization; and (c) expanding rescrch programs. As the available statistics on both energy resources and consumption are limited the Bank Group has funded a number of studies on energy supply and demand: work on electricity demand in Java was financed under Credit 399; hydropower potential is being investigated under Loan 1365; and a sector management information system will be financed under Loan 1513. More recently, the Minister of MME asked the Bank to undertake a more comprehen- sive survey of the energy sector with a view to systematizing the data currently available, identifying the major deficiencies and assisting GOI to determine the best method of proceeding with sector development and policy formulation. A mission visited Jakarta in November 1980 and again in March 1981 and its draft report has been forwarded to GOI. It is expected that extensive discussions will follow. 33. Among the issues facing the sector is the system of energy pricing. Subsidized petroleum product prices have caused serious distortions in the economy by failing to reflect the opportunity cost of these products to the - 11 - economy. The effects of this have been to favor the use of oil over other competing fuels, the promotion of domestic consumption over exports, and, because the degree of subsidy between oil products is uneven, to distort demand between individual petroleum products (para. 11). The Bank has had a continuous dialogue with GOI on the question and has highlighted the consequences of this policy in its economic and sector work. The energy sector survey (para. 32) is also expected to assist GOI in formulating a global energy strategy encompassing the pricing issue. In recent discussions with the Bank, GOI has expressed its intention eventually to eliminate the subsidies subject to maintaining poor consumers ability to satisfy their energy needs. In fact, a major step was taken in this direction in May 1980 when the price of gasoline was increased to the international level. However, while kerosene, diesel fuel and fuel oil prices were also increased, they remain substantially below world market prices. The Electricity Subsector 34. The electricity subsector is regulated by the MME through its Directorate General of Electric Power (DGEP). The subsector comprises (i) PLN (discussed below in detail), (ii) captive plants installed by private parties for their own use, (iii) small municipal franchises, and (iv) a small number of cooperatives which were set up to provide electricity in remote rural areas. 35. PLN Background. PLN is a public corporation (Perum) constituted under Presidential Decree No. 18 of 1972, with responsibility for the gene- ration, transmission and distribution of electricity and the planning, construction and operation of electricity supply facilities. Until 1979 these responsibilities were exclusive to PLN, but in that year, with the objective of facilitating the exploitation of electric power, GOI enacted legislation allowing the intervention of private entities and cooperatives in the sector under license from MME; thus far, no such entities have been so licensed. 36. PLN is managed by a board of directors headed by a president director, who is appointed by the President and is accountable to the Minister of MME. The president director has authority for all day-to-day operations of PLN. The board currently comprises five other directors with functional responsibility for planning, construction, operations, finance and administration. Operational responsibility devolves to 16 regions, and capital project responsibility to a number of project managers. 37. Thus far the preponderance of decision making and control has been retained at headquarters, but the growth in size and geographical dispersion of PLN's operations has made this form of management increasingly inappro- priate. The Minister has required PLN to review its management structure with the two principal objectives of decentralizing more responsibility to - 12 - the regions and rationalizing headquarters functions. The project will support this initiative by providing management consulting services to elabo- rate the new machinery of management control and to engineer the necessary changes in the systems of accounting and financial control. 38. PLN's Market. Past records on PLN's market are limited to PLN's sales which, because of the very low levels of consumption and the severe restrictions and interruptions affecting service, reflect PLN's ability to supply rather than potential demand. A study to assess potential demand in Java was undertaken in 1974-76 by consultants financed under an early power project (Credit 399); with adjustment this is currently used by PLN as the basis for investment planning in Java. It suggests that PLN's sales growth will be limited only by its own ability to supply until about 1986, when full market penetration will be achieved; thereafter, sales growth in Java will be delimited by growth of the market itself. Similar studies are currently in progress in Bali and Sulawesi, and one is planned for Sumatra. Thus, while market size is unlikely to be a constraint on growth within the lead times of the facilities PLN is currently beginning to construct, PLN must take steps to ensure that its future investment decisions are based on sound market knowledge. PLN is building its market survey capability and taking steps to ensure that regions play their proper role in demand forecasting; the power sector management information system study funded under Loan 1513 will clarify planning relationships between PLN, the MME, and other concerned agencies. 39. Existing PLN Facilities. Until the early seventies, the expansion of PLN-s facilities was constrained by the foreign exchange shortages Indone- sia faced. Accordingly, a crash program of development was instituted based largely on gas turbines; these still comprise about 30% of the total capacity of 2,610 MW. However, this imbalance in plant is being corrected; as part of its present program, 1,000 MW of new steam capacity will be commissioned by PLN by 1982 and a number of hydroelectric projects are under implementation. 40. PLN also operates over 6,000 km of transmission lines at 70 and 150 kV and about 47,000 km of distribution lines, the bulk of which are in Java. About 2,000 km of 150 kV transmission lines under construction are scheduled for completion by 1982; Java will have a fully interconnected grid at 150 kV by 1982. A 500 kV system covering West and Central Java will be commissioned by 1984 and extended throughout Java thereafter. 41. PLN's Development Plan. PLN follows the practice of preparing annually a ten-year development plan to cover the projected requirements of generation, transmission, distribution and other facilities. The latest plan covers the development period FY81 to FY90. It has been formulated on the basis of the following objectives: (a) optimize domestic resource utilization by substituting use of oil by coal, hydro and geothermal resources for power generation and by reducing the use of fuel-inefficient installations; - 13 - (b) realize economies of scale through larger-sized installations; (c) achieve operational economy by coordinating the utilization of plants through interconnected operations; and (d) achieve and maintain acceptable standards of reliability of supply. 42. PLN has recently developed in-house capability for carrying out least-cost generation planning studies with computer modelling and this has been employed to arrive at the development plan for Java, which is expected to continue to account for about 80% of PLN's electricity sales through the 1980s. Planning for the Other Islands has hitherto been carried out by less sophisticated methods, but with increased involvement of the regions in the planning process and the strengthening of the computer data base which is now in progress, a significant improvement in the quality of Other Island planning is expected over the next two years. Through PLN, GOI reviews the development program each year with the Bank. PLN now urgently needs to establish a financial plan to match its development plan: the necessary steps are described in para. 46. 43. On the basis of the present knowledge of the market, the overall rate of growth of sales envisaged in PLN's plan is an average of 22% per year through 1983, falling to 16% by 1989. One condition for achieving these targets will be PLN-s ability to implement an adequate connection program. To address this PLN had agreed under Loan 1513 to prepare and furnish to the Bank for its review its annual consumer connection program and thereafter implement it in a satisfactory manner. This is being done. 44. PLN's development plan shows generating capacity increasing from 2,610 MW to over 9,500 MW by the end of the decade. The greatest part of the increase (4,300 MW) will be in the form of thermal plants; by 1989 they will contribute over half the generating capacity and all of those to be planned from now on will be coal-fired. New hydroelectric plants will add 1,500 MW, over 20% of the additional capacity. Together with associated transmission and distribution facilities, projects to be completed through FY89 are estimated (at constant 1980 prices) to cost a total of $7.4 billion, of which $4.5 billion would be in foreign exchange. 45. PLN's Financial Results. PLN operated at or near breakeven in net income terms for five years through FY80 (ended March 31,1980). Its invest- ment program accelerated rapidly during this period and by FY80 capital expenditure was running at over Rp 300 billion annually - more than twice sales revenue. With negligible net earnings, PLN's only sources of internal funds have been depreciation retentions and customers- connection fees, which funded 21% of capital expenditures over the last five years. GOI provided the rest of the funds required, mainly in the form of equity capital, though recently the onlending of funds from international lenders has formed an increasing proportion of GOI funding to PLN. PLN has agreed under past power projects that it would attain by FY86 a level of contribution to its investment program from internally generated funds of not less than 30% - 14 - (implying a rate of return on revalued assets of approximately 8%); this contribution target has been reconfirmed by PLN. Indicative target levels of contribution for the intervening years have also been adopted: 12% for FY80-FY82; 20% for FY83-FY84; and 25% for FY85. PLN achieved its indicative target comfortably in FY80 and FY81 and is expected to do so in FY82, mainly because of the introduction in May 1980 of a new tariff schedule to which the Bank contributed extensively. Attainment of the indicative targets for FY83 through FY85, and the covenanted level for FY86 and beyond, will call for a further tariff increase of about 20% in real terms in FY83. Since loan financing is a relatively recent innovation for PLN, its debt:equity ratio stands at the conservative level of 17:83. The current ratio is 4.7, and with assets including Rp 100 billion in cash, the authority's liquid position is satisfactory. It has been agreed that PLN will maintain a debt:equity ratio of 60:40 or below and a debt service coverage of 1.3. 46. PLN's investment program is now of such a size that its financial implications must be reviewed with equal care with technical and economic considerations, and a judgment made of the feasibility of the proposed investment in terms of the requirement for capital funds, and the level of revenues necessary to meet associated operating costs. Then, PLN needs to develop a financing strategy which will give it the greatest assurance of the availability of funds for its capital program. Although legally entitled to issue obligations and borrow in its own right, in practice PLN obtains all its external funding from GOI. But GOI's commitment of funds is limited to the fiscal year's budget, whereas the lead time for many of PLN-s projects is 4-6 years and its overall investment planning period is 10 years. In consultation with the Bank, PLN is alqo engaged in an explorat±on of the extent to wh.ich it could prudently increase its debt:equity ratio over the next few years. At negotiations, it was agreed that PLN would, as part of its annual planning procedures, (i) institute a ten-year financial forecast based on its proposed development plan; (ii) test each development plan for financial feasibility; (iii) develop a financing plan covering the first five years of the forecast period; and (iv) ensure that its recommended development plan and associated financial forecast and financing plan are reviewed by the GOI and the Bank (Section 4.07 of the draft Project Agreement). In addition GOI agreed to take appropriate measures to facilitate access by PLN to the sources of finance it requires (Section 4.02 of the draft Loan Agreement). 47. PLN-s Performance Under Previous Bank Group Lending. The Bank Group has provided $1,135 million through ten different loans and credits for power generation/distribution facilities in and around Jakarta and in West and Central Java. Specifically, three distribution projects (Credits 165 and 334, and Loan 1259) have been approved for the rehabilitation and expansion - 15 - of the distribution facilities in the greater Jakarta area and seven power generation projects (Credit 399, and Loans 1127, 1365, 1513, 1708, 1872 and 1950) in West and Central Java have been undertaken to help PLN expand the Java network. Past loans and credits also provided funds for various consulting services for management studies, demand studies and feasibility studies. 48. Out of the ten projects four have been completed, two are nearing completion, and four are in the early stages of construction. PLN's perfor- mance in implementing these projects has been uneven at first but has signi- ficantly improved later. The earlier distribution projects (Credits 165 and 334) were completed more than three years behind schedule. A Project Performance Audit Report on these two projects, which was issued in November 1979, concluded that despite the delay in project completion (which in large measure was attributed to the unfamiliarity of the Bank and the borrower/ beneficiary with each other's procedures), the projects made possible a greater reliability of supply and many institutional and operational improve- ments. In generation projects, the earliest project (Credit 399) covering the first and second units at Muara Karang was completed about two years late; the next (Loan 1127) for the third unit, less than one year late. Subsequent generation projects at Muara Karang (Loan 1365) and Semarang (Loan 1513) are about 4-6 months behind appraisal schedule; two projects at Suralaya (Loans 1708 and 1872), although still at an early stage, are also a few months in arrears. The record of implementation of agreements reached in connection with these operations has been satisfactory. PLN can be considered today as a mature and reliable undertaking. 49. The improvement in PLN's performance in project management is however in danger of being negated by delays which are beginning to arise in procurement as a result of new procedures introduced by the GOI in 1980. These procedures affect all except the smallest contracts and experience is similar in most other sectors in which the Bank is involved. A remedy is being sought in the context of the ongoing Bank/GOI dialogue on project execution. PART IV - THE PROJECT 50. The Jabotabek Transmission and Distribution project is part of the Java System Development Plan, formulated through earlier Bank loans to PLN and recently updated. The plan calls for a total investment in transmission and distribution of about $1,500 million by 1985 (1980 prices). The distribution component is based on a feasibility report prepared in 1980 by SOFRELEC of France. Planning for the transmission component has been carried out during 1980-1981 by PLN-s newly organized system planning organization. A Bank mission appraised the project in March 1981, and negotiations were held in - 16 - Washington in September 1981; the Indonesian delegation was led by Mr. Ir. Abdul Kadir (DGEP). Supplementary data are in Annex III. The Staff Appraisal Report (No. 3468-IND) is being circulated separately to the Executive Directors. Project Objectives 51. The main objectives of the project are to increase PLN's trans- mission and distribution capacities, enable grid extensions to be made to rural areas, and provide consultancy services for schemes which will enhance the use of coal, develop an effective grid system and continue PLN's institutional growth. Project Description 52. The project comprises: (i) a distribution system for Jakarta and the regencies of Bogor, Tangerang and Bekasi (Jabotabek) in West Java involving about 450 km of 20 kV cables, 760 km of 20 kV overhead lines, 1,336 substations and 800 pole-mounted transformers, about 5,300 km of new low voltage lines and some 320,000 service connections; (ii) a high-voltage (HV) system, complementary to (i) above, involving five new sub-stations in Jakarta, 46 km of double- circuit 150 kV cables and 980 MVA of transformers; (iii) engineering of the next base-load coal or multiple-fired thermal power units in Java; (iv) engineering of the Extra High Voltage (EHV) Central-East Java transmission line; and (v) management consultancy for further improvements in PLN's financial planning and control systems. Evolution of the Project 53. Reinforcement and expansion of the distribution system of the City of Jakarta - a densely populated (5 million) urban center covering 200 sq km - was carried out under the Bank's first two lending operations. Its completion was followed by the fifth operation (Loan 1259 of 1976) for extension of the distribution system to about 2,800 sq km of Jabotabek. This project will be completed by 1981. Part (i) of the proposed project is intended to extend electricity supply to both urban and rural areas of Jabotebek-s 5,700 sq km (with a population of 10 million) and represents a - 17 - continuation of the Bank's development efforts in an important area of PLN-s operations which accounts for about 40% of its electricity sales. SOFRELEC carried out the feasibility study of requirements of the region during 1982-1990. The distribution component, for the period 1982-1985, is based on the report on this study. SOFRELEC also pointed out the need for complimentary reinforcements of the high voltage (150 kV/70 kV) system in the Jabotabek region to meet the growth of demand. PLN has in the past been primarily responsible for planning and implementation of schemes of high voltage system expansion and it has done this successfully using consultants only in some areas of specialization. The project component described in part (ii) of para. 52 above, is based on detailed system studies carried out by PLN and covered in its March 1981 "Report on reinforcement of the Jabotabek H.V. system during 1982-85". 54. The project component described in part (iii) of para. 52 above is a further step in implementing the country's energy policy of utilizing coal instead of oil for electricity which began with the Suralaya Thermal Power Station project (ultimately 3,100 MW) under implementation in West Java with Bank assistance through Loans 1708 and 1872. Two units each rated at 400 MW are currently under construction at Suralaya. PLN is studying the feasi- bility of installing a third unit of 400 MW at this site by 1987. A feasi- bility study to establish a similar (ultimate 4,000 MW capacity) site in East Java was initiated as part of the Bank's seventh operation in the electricity sector (Loan 1513) and is now nearing completion; a site near Tuban has been chosen. The first generating set at Tuban (400 MW) is required to be commissioned in 1987. To achieve this, detailed engineering has to commence early in 1982. GOI has requested Bank financing for the purpose. At negotiations assurances were given by GOI that the sources of coal for the mext base-load coal or multiple-fired thermal power units will be identified by June 30, 1982, and that arrangements for mining and transport of coal required will be implemented in time for their commissioning (Section 3.06 of the draft Loan Agreement). 55. The first steps toward development in Java of an effective grid system at 500 kV were taken during the Bank's eighth and ninth operations. An 800 km line extending from West to Central Java is under construction, scheduled for completion during 1983-84. The 300 km extension to East Java is required by 1985. GOI has decided to use bilateral financing sources for construction but has requested that the Bank finance the engineering primarily to ensure uniformity in approach on the features of the EHV grid. The project component described in part (iv) of para. 52 above provides for this. Assurances were obtained at negotiations that GOI and PLN will take all necessary steps to construct the Central-East Java EHV line by December 31, 1985 (Section 4.04 of the draft Loan Agreement and Section 3.06 of the draft Project Agreement). Implementation 56. The project will be implemented by PLN during 1981-85. The detailed engineering of the project component described in part (i) of para. 52 above - 18 - (the distribution component), covering preparation of bid documents, evalua- tion of bids and supervision of construction has started and will be carried out entirely by PLN which has now acquired the necessary experience. The construction organization built up during the past few years will be adequate for this project. Detailed implementation and milestone schedules have been prepared. Bid documents for the first lot of equipment were issued in July 1981 after review by the Bank. No major problems are foreseen in the construction of this part of the project but progress will have to be monitored by the Bank, particularly on procurement, as PLN will be undertaking work entirely on its own for the first time (Section 2.07 of the draft Project Agreement). 57. The project component described in part (ii) of para. 52 above (the 150 kV high-voltage component) will be implemented by PLN with the assistance of consultants in some specialized areas as in the past. The West Java Transmission Project unit was set up for PLN's ongoing construction program of 150 kV transmission lines, cables, and sub-stations (including the first two gas-insulated substations). It will be responsible for construction of the project component described in part (ii) of para. 52 above. The unit has a dynamic experienced manager, and a nucleus of supporting staff; Preece, Cardew and Rider (PCR) of the UK acts as the consultant to this unit. The same organization pattern will be used to execute the new project. The Bank has no objection to this arrangement. PLN has started to mobilize the required consulting services immediately to meet the construction program. PCR's engineering services covers 360 man-months at an average man-month cost, including basic salary, overheads and fees, international travel and overseas allowance for resident field engineers, of $10,000. It is based on rates anA costs prevailing it present. No difficulties are expected in the implementation of this project component. The land required for the five new substation sites has been acquired and a guarantee from the DKI Jakarta has been obtained that PLN will be given right of way for the proposed cable routes. 58. The detailed engineering, as described in part (iii) of para. 52 above, of the next base-load coal or multiple-fired thermal power units in Java up to the stage of preparation of bid documents will be carried out. It is estimated to require about 400 man-months of expatriate effort at a man-month cost of about $8,000. The estimate also provides for about 128 man-months of local consultants at an average cost of about $1,500 per man-month. 59. Concerning part (iv) of para. 52 above, PLN proposes to use consultants primarily for construction supervision of the EHV line extension. About 70 man-months of expatriate effort will be required at a cost of about $7,000 per man-month. Local consultants will also be used at an average cost of $1,500 per man-month. The management consultancy work under part (v) of the project is estimated to require 45 man-months of expatriate effort at an average man-month cost of $13,000. - 19 - Costs and Financing 60. Total project costs are estimated at $319.4 million, of which $206.0 (64%) is in foreign exchange. The proposed Bank loan of $170.0 million will finance 53% of total project cost. The remaining part of the foreign exchange cost will be met by GOI. Detailed bills of quantities of equipment required have been prepared. Basic prices have been determined from material and construction costs for ongoing transmission and distribution projects at levels prevailing in November 1980. Physical contingencies of 5% have been allowed for. Price contingencies were estimated as follows: on foreign costs at 9% for FY82, 8.5% for FY83, and 7.5% for FY84 and 85; and on local cost at 18% for FY82, 14% for FY83 and 10% for FY84 and 85. 61. This project is a subcomponent of PLN's 1982-85 Transmission and Distribution Program of $1.4 billion. The foreign exchange requirements of this program amount to $778 million of which the proposed Bank loan would provide $170 million, $40 million would be forthcoming from ADB and $58 million from commercial credits. It is expected that the GOI would seek other commercial credits or bilateral/multilateral sources for the remainder. 62. As in previous operations, the proposed Bank loan would be to the GOI which will onlend the proceeds to PLN on terms equivalent to those of the Bank loan; the foreign exchange risk will be borne by GOI. Signing of the Subsidiary Loan Agreement will be a condition of loan effectiveness (Section 6.01 of the draft Loan Agreement). Procurement and Disbursement 63. All equipment and materials to be financed through the proposed loan (other than poles for the distribution expansion project) will be procured through international competitive bidding in accordance with Bank guidelines. As some participation by Indonesian manufacturers is likely, a 15% preference on the c.i.f. price, or prevailing duties, if lower, will be applicable. For economy it has been proposed that the procurement of con- crete poles be arranged through local competitive bidding in accordance with GOI procedures. Adequate competition is expected from recently estab- lished and growing local industries to obtain prices which are expected to be significantly lower than the alternative of importing either steel or concrete poles under ICB. 64. The Bank loan will be disbursed against the following items: (a) equipment (except poles) - 100% of foreign expenditures for directly imported goods, 100% of the ex-factory cost (excluding any identifiable tax) for locally manufactured goods and 65% of the total expenditures for imported goods procured locally; (b) concrete poles - 80% of the expenditures, representing the estimated indirect foreign cost, and (c) consultants services - 100% of expenditures. No disbursements will be made for expenditures prior to loan signing. - 20 - Benefits and Risks 65. The project will increase the capacity of PLN's supply facilities substantially in a crucially important area of its operations. The project itself will have an internal economic rate of return of at least 18%. There are no unusual risks. Ecology 66. No environmental problems arise in connection with the project. In congested areas the 150 kV system and the medium-voltage system will be underground. The 150 substations will be of the compact gas-insulated type appropriate in such locations and medium-voltage transformers will be located in kiosks. In less congested areas both the medium-voltage and low-voltage systems will be overground. PART V - LEGAL INSTRUMENTS AND AUTHORITY 67. The draft Loan Agreement between the Republic of Indonesia and the Bank, the draft Project Agreement between the Bank and PLN, and the report of the Committee provided for in Article III, Section 4 (iii) of the Articles of Agreement are being distributed to the Executive Directors separately. 68. In addition to the special features of the Loan and Project Agreements whUch are re_erred to in Section III of Annex III, an additional condition of effectiveness of the Loan (para. 62 above) includes that the Subsidiary Loan Agreement has been signed on behalf of the Borrower and PLN. 69. I am satisfied that the proposed loan would comply with the Articles of Agreement of the Bank. PART VI - RECOMMENDATION 70. I recommend that the Executive Directors approve the proposed loan. A. W. Clausen President by E. Stern Attachments October 22, 1981 Washington, D.C. - 21 - ANNEX I Page 1 of 5 INDONESIA - SOCIAL INDICATORS DATA SHEET LAND AKEA (THOUSAND 50. ) INDONESlA REFERENCE GROU PS (WEIGH TED AVgRAGES LAND AREA (THOUSBAND S.1 - MOST RECENT ESTIMATE)' a_ TOTAL 1919.3 MOST RECENT LOW INCOME MIDDLE INCOME AGRICULTURAL 2t6.4 1960 /b 1970 /b ESTIMATE /b ASIA PACIFIC ASIA 6 PACIFIC GNP PbR CAPITA (ULS) 80.0 140.0 370.0 232.3 1136.1 ENEKGY CONSUMPTION PER CAPITA (KILOGRAMIS OF COAL EQUIVALENT) 130.1 128.4 237.1 499.4 1150.6 PUPULATION AND VITAL STATISTICS POPULATION, MID-YEAR (THOUSANDS) 94680.0 116143.0 142870.0 URbAN POPULATION (PERCENT OF TOTAL) 14.6 17.1 19.8 17.3 40.8 POPULAT1ON PROJECTIONS PUPULATION IN YEAR 2000 (MILLIONS) 219.7 STATIONARY POPULATION (MILLIONS) 388.0 YEAR STATIONARY POPULATION IS REACHED 2110 POPULATION DENSITY PER SQ. KM. 49.3 60.5 74.4 153.6 373.1 PER SQ. KM. AGRICULTURAL LAND 355.9 417.9 487.3 360.3 2382.8 POPULATION AGE STRUCTURE (PERCENT) 5-14 YRS. 40.7 44.0 40.8 37.4 39.8 15-64 YRS. 56.2 53.5 56.3 59.2 56.7 65 YKS. AND ABOVE 3.1 2.5 2.9 3.5 3.5 POPULATION GROWTH RATE (PERCENT) IOTAL 2.1 2.0 2.3 2.1 2.3 UKBAN 3.7 3.6 4.0 3.4 3.8 CRUDE BIRTH RATE (PER THOUSAND) 46.7 40.8 36.2 27.7 29.7 CRUDE DEAIH RATE (PER THOUSAND) 24.8 17.7 13.3 10.2 7.5 GROSS KEPKODUCTION RATE 3.0 2.8 2.3 2.5 1.9 FAMILY PLANNING ACCEPTOKS, ANNUAL (THOUSANDS) .. 181.1 2216.0 USERS (PERCENT OF MARRIED WOMEN) .. 0.2 27.1 20.4 44.1 FOOU AND NUTRITION INLtX OF FUOD) PRODUCTION PER CAPIIA (1969-71-100) 93.0 102.0 103.0 107.1 123.7 PER CAPITA SUPPLY OF CALORIES (PERCENT OF REQUIREMENTS) 89.0 92.0 105.0 98.6 112.6 PROTEINS (GRAMS PER DAY) 41.0 41.0 47.0 56.9 62.5 OF WHICH ANIMAL AND PULSE 6.0 6.0 6.0 14.2 19.7 CHlLb (AGES 1-4) MORTALITY RATE 31.2 20.4 13.7 14.6 4.8 HEALTH LiFE EXPECTANCY AT BIRTH (YEARS) 39.0 46.7 53.0 57.7 64.0 INFANT MORTALITY RATE (PEP THOUSAND) 159.0 126.0 120.0 89.1 50.2 ACCESS TO SAVE WATER (PERCENT OP POPULATION) TUTAL .. 3.0 12.0 30.1 45.9 URBAN *' 10.0 35.0 65.8 68.0 RURAL .. 1.0 6.0 20.1 34.4 ALCCSS TO FXCRETA DISPOSAL (PERCENT OP POPULATION) TUIAL .. 12.0 15.0 17.6 53.4 URBAN .. 50.0 60.0 71.0 71.0 RURAL .. 4.0 5.0 4.8 42.4 POPULATION PER PHYSIClAN 46778.7 26498.5 13644.4 3857.7 4428.7 POPULATION PER NURSING PERSON .. 7672.8 8851.9 6411.8 2229.7 POPULATION PER HOSPITAL BED TOTAL 1364.1 1644.6 1606.0 1132.8 588.5 URBAN 251.8 .. 697.3 322.3 579.6 RURAL .. .. 3159.0 5600.5 1138.5 ADMISSIONS PER HOSPITAL BED .. .. 22.4 hOUSING AVERAGE SIZE OF HOUSEHOLD rjlAL 4.4 4.8 URBAN 4.9 5.3 RURAL 4.3 4.7 AVERAGE NUMBER OF PERSONS PER ROOM TOTAL .. 1.5 URBAN .. 1.6 RURAL .. 1.3 ACCESS TO ELECTRICITY (PERCENT OF UW_LLINGS ) TUlAL .. .. URbAN .. .. ACRAL .. .. - 2 2 - ANNEX I Page 2 of 5 INDONESIA - SOCIAL INDICATORS DATA SHEET INDONESIA REFERENCE GROUPS (WEIGHTED AVERAGES - MOST RECENT ESTIMATE)r MOST RECENT LOW INCOME MIDDLE INCOME 1960 /b 1970 /b ESTIMATE /b ASIA & PACIFIC ASLA & PACIFIC EDUCATION ADJUSTED ENROLLMENT RATIOS PRIMARY: TOTAL 71.0 78.0 94.0 85.9 99.8 MALE 86.0 83.0 100.0 94.4 100.6 FEMALE 58.0 73.0 89.0 64.5 98.8 SECONDARY: TOTAL 6.0 16.0 22.0 38.0/aa 53.5 MALE 10.0 21.0 27.0 34.6/as 58.4 FEMALE 3.0 11.0 18.0 18.0/as 48.6 VOCATIONAL ENROL. (C OF SECONDARY) 20.0 22.0 20.0 3.8 21.1 PUPIL-TEACHER RATIO PRIMARY 39.0 29.0 30.0 32.8 34.2 SECONDARY 14.0 13.0 17.0 19.9 31.7 ADULT LITERACY RATE (PERCENT) 39.0 56.6 62.0 52.8 86.5 CONSUMPTION PASSENGER CARS PER THOUSAND POPULATION 1.0 2.1 3.5 1.7 12.7 RADIO RECEIVERS PER THOUSAND POPULATION 7.2 22.0 38.5 35.3 174.1 TV RECEIVERS PER THOUSAND POPULATION 0.1 0.8 7.3 3.7 50.6 NEWSPAPER ("DAILY GENERAL INTEREST") CIRCULATION PER THOUSAND POPULATION .. .. 17.7 14.6 106.8 CINEMA ANNUAL ATTENDANCE PER CAPITA .. .. 0.8 3.4 4.3 LABOR FORCE TOTAL LABOR FORCE (THOUSANDS) 34752.5 41034.6 50929.1 FEMALE (PERCENT) 27.9 31.0 29.5 29.3 37.4 AGRICULTURE (PERCENT) 74.8 66.3 59.1 69.8 50.2 INDUSTRY (PERCENT) 8.4 9.7 11.8 14.1 21.9 PARTICIPATION RATE (PERCENT) TOTAL 36.7 35.3 35.6 39.7 40.2 MALE 5'4.1 49.5 5C.i 51.5 49.8 FLMALE 20.0 21.6 21.1 23.3 31.1 ECONOMIC DEPENDENCY RATIO 1.2 1.3 1.2 1.1 1.1 INCOME DISTRIBUTION PERCENT OF PRIVATE INCOME RECEIVED BY HIGHEST 5 PERCENT OF HOUSEHOLDS .. 33.7/c 23.5 HIGhEST 20 PERCENT OF HOUSEHOLDS .. 52.07W 49.4 LOWEST 20 PERCENT OF HOUSEHOLDS .. 6.87 6.6 LOWEST 40 PERCENT OF HOUSEHOLDS .. 17.37W 14.4 POVERTY TARGET GROUPS ESTIMATED ABSOLUTE POVERTY INCOME LEVEL (US$ PER CAPITA) URBAN .. .. 136.0 134.1 248.6 RURAL .. .. 112.0 111.6 193.7 ESTIMATED RELATIVE POVERTY INCOME LEVEL (US$ PER CAPITA) URBAN .. .. 119.0 .. 249.8 RURAL .. .. 98.0 .. 234.3 ESTIMATED POPULATION BELOW ABSOLUTE POVERTY INCOME LEVEL (PERCENT) URBAN .. .. 28.0 41.7 21.2 RURAL .. .. 51.0 51.7 32.2 Not available Not applicable. NOTES /a The group averages for each indicator are population-weighted arithmetic means. Coverage of countries among the indicators depends on availability of data and is not uniform. /aa China included in total only. /b Unless otherwise noted, data for 1960 refer to any year between 1959 and 1961; for 1970, between 1969 and 1971; and for Most Recent Estimate, between 1976 and 1979. /c Income recipients. May, 1981 -2 3 -NEX Page 3 of 5 DEFINITIONS OP SOCIAL ISOICATORS Notes: Alt!,ough the aaer drw rnsnrm eealyjde tens uhoiaiead rlale isoudaa h a tha, they onou Ininer nainll opaal hams ftelc isanadtddfntosedcoctt adb itrn onneai oletn the data. Tn _oh _c I_ thte,ostlcdac h odn f aoide nIat rns,edcerneie etI ajrdftt_a Th eeec rusar l h oecaty ea dtesbetconr n rotr ru ihsmeot ihroeaeIcm toIh onr ru of thIy1_I le-sb otcoor nac fo 'Capitldtartldia -10 Enoters", trou dhleftf--tnoaboit .r c anbOdLe.. -at-a- osnloin fsro Tna oa uft ace erwa ooptao Lore a an.u.n etr. irha...,lg end rural)t dIotde by thier roaceod h,-sIlrliyh ytohd tie crp,pnoe.nrhtedkthngren rt I alw .1979. dot. el Ioti ceters fomitl aeI esthiaasut eronoly.of. coeindted., hy ecieoononebo sheio ast yoed twkiie(97-1hae;lI,adndcl etr.opytaetyeafa yapyoca hrh 1970,RE end 1909 :data. ed tol ewisnat, irs nint,ec)othofe npnln con fro hosptwi diide by thei.. Enobliher f eA. -d. Z y_- POPOLOTIOS iota liTal. Sdl-ATiiOIittdd. -I -pl:%,h..... heIl -11difrn b .. hdLdefntoso reaenm y Afetoaaakl fdn ndternbmal.Ahadro lodgnr nap obmay not heInlode i 19700 coud neie9 196. 97, ad 97ddaa.th ho .et. for . ttnaicaifpurpoam.)hihf-M Potulenio in fee dill - oroent ppulatio rjoio aee hae.n10 e f esn e oni alubndn ua ocupedcounttow tIotati ppntn byaeadsaedtetmraiynd fenlyrae.deeLig.- repe iboehy anlignnidet, estntnotcen esters for tenth m MdYra_te . I. a -mohon the .lyeneis 960tusing denid ft7 Hof oa,mOn r orideilgos iey Stationery 960 170 -eoaie-nan meaty pd usio. hrei o rnb -c . ri.r shh.w. -.l tonal mae n fisGos otl,sleso n the httb fet .a.. ln h ~Sae adea h g tutr r-srisn fater an th pinn mont e:1 pecetae of. rercIn-- sent lifse.pl. eucninyqurnntlestfor ahr o aprve piacyinriton Test setnnr coouleiif is:~ rea.e - 1bl.. . 75Y- The.etat ttneypplnu p r...Ide gdrarlI.,vumionael, orteat Isr tominig lo..ttuct innsfor upi fotnistion tesaito secluded.i, , d .l1 ..Iil. ee 'ily only 1960,y 197 and 1978 .dnra. IfP..i.-il f - iy MCTONi-eae ei rmr.sdstnwoTtlsner toidi PorLatio ..has...l. Inuar I .e.oa it Ch ldrn(y 1 peers),.lt.L sorhir-age 1t - prier ed ecndr -ole .diied y1 uner of dahr inth th4 iyear . I)q, end retred (6 persan uer a pInd oneofmi-ya p.p. coresponIng le els. l,pltel lanton; 1960, 1970, ead 1979. dane.L. d-l.. . iitltrcLaebatn)-tnrn dltsdebt noh red~ ad ariSe Lbralepnoirneth, tanI.-I feil -ltta Lpd-tannualgreth, care of y. totltid dspaer Ledo tota adoff tIppltion age ,iT yeasad e yaso popoisoinos fur itlO-Od,ith 19..6I6-70,- -andte1970-79.- lenonafor195-6h iCOl-Ot1.en i90-9 'Peasme CreSer hosed o1tstw) Pssngr ar capis et populnh,o yNh, 1970, end 1979.lfdI. ffriit ..L dat. al ier eh-hotlne. i .p.Id. y; I'l trd_enL aeSe hned -Ana etsprtosnso aid-yar P ditteoiveraq bee thousan roueIon) -.L il typesd of nciner fr d populaion; 196.p197. and 197 L-date. y- h. p. .i. . bn idtast to.. gsoers p--io pe. hosn 1 -h pt-i eiot; e-nclad.s on-p.i Oil6Sit 19e0es .usually fineteen anera-e ending in-190,i197.,.add.979..meatyo-anTtts aboIte:dIlinensiIg 64eyiinfianoidoa-isat (65erceor d-l I ofidrideys)Ps..toe t pripad ircouaopeeadin leel rnargitainfT ess mameLe. of9ohil-hea7io age (1-79 6 tea.. h s it-cnoidorsn ewatas Cio Le-io (oarth ...o pulaton -t Shone the l.ad or FOl tLLhetOTM.ITtle toh..bed f'dai..ly i i appears n7.po las_ Sotnse.asek te es -ecadd)-tAggregte. peiuf oo echcunr isL... F- basd o LAbO l P IIIL;OCt, Y.. y-b.-PL.l netorlavrat podoertros eihts fi_-5,197,Ind1979 dsia. Totl tabo PoeceI: (toubne -'. ILEmcll cie esn, uid tiiyet . day. .Anieble --pios conpeta g O Imes9i poutn, ipo bs w oprbe 9g 91ed17 aa enpoonPI sod- -t- _ changS.instink .tIe Aupp ..e Inld seib- Ifeed, - sees, e -is we-et p- them...p pshor tonne T as er..eg of-- tota b.leor foc. IfubithitIsses1d-in food-p-esing, and ases ..In d-ilyripuni.. L.aqoire-. gar...i-1 ponooli n pe Labor. force p.-in_emtg. fr. y butig n hoisehold level lShi-bT, tITO end 1977 data 1970t and -Li L ON date.Y., If Per1 c fole i=eapo ltn ro9toi (gram rety d) - roei content- of pert. cita ,:, Paricnaiwo ansirj.ers - thota.u al,and tamaei ) S- h.e-etnipa lowo ne upl ffodpr a_t_nsppyo fo sdeieLa hvs s anv_yeearcseeda otl al,ed eee ao frea v dtmis o l outiseeaia y SApoid w.iimmpren I Ydfnis,el tAfml oplto fnil. agsrepcinei_Ly; sibnace f 0 gas o taniproei pe dy nd 0 ram e aisa ad 160 190.an.199 .ame .Tes arMbse on t' pati ipto rates pole proein,of nioh 0 grme sowidhe atmeiprotin. heseesn- reisot iog age-sen strctuee of tbn. pouaionP,Iadln ieted Cild leas -1-6nd t aiy Pate beer Cltiheumand) p:- nLy deth par g tooseod in Pecedce fbl P-ivt..coa(ohi ehadhid erndb ihs iwie dat deie fics laetbles 1960 Li97 an 17 dt. ff..uaebldd et bIrth; 1960. 1970 and 1979 daoa. and should he intnrprened with nenaidarsbieoaoninn.~~~~~~~~~~~~~~~~~~~~~~~~~~~~~~~~~f ..~ i ofnterel.irnlSetsI Owenthosn)-ana deahsofinfntlods one ear OstiaLe AIl olre P err lema Lefnii05 -pe reIna -oranland rtL - of age l pee: d. thouandlOo biths.ib lat poare inom leve is7 that icm eelhm nfh oi Aiest taelae fI_eo f nulton-mel thn.. aa e- irtosleeot dierF 1 (.l.t 1.0 plus esenilno-food trsv Ite baot is-no her of .. h peoleI Ioal urban an Nuret mothi. rF-ebesrs S fodbe asteritipp1 fitideLe fteatpd surfangneteI.... orun .treaedbuni e.Rcoseiwna tAti-sted. (aisn .v Pnsn Ib-rfem Leve f(il,pe c ofalt,y h-oting madrua - sanr -uc a .thee fro pyFOtb.roed otiolsy,spings, sod eseitr 1 w lls) asihieesniv p neetygb incom lee isb one-hir of60 1onr7 g per 197 pits percetage cflthe roastr populations. L Ieo banrey uli eroa-irmao vsconr. fos l.em l s deined .. fr-nt-inura fondt or stadpenbote nrbet tan20 meters from a be11useg mayetII be nnde dleigh tadjustmen for hgher coto Inin in or lbs soef.,c; reasonable acess1 woldipl6 in1 hehoswieit5sbr of70the dh1usadold and7 reral dsoa. fpouain(nbnadrua)eoar a.l lubadf api tpa.Lubn aNet rural) Ifefd by secrete dispnsalasl,.Z L,r.,d - I1 rh nlsoinma isoa, obeb orwihnat byrUeeAsp,, olf hesanetreeIengtoandenIaf Omfa bivisi y lee insosiletters. Stat 1961~~~~~~~~~~~~~~~~~~~~~~n.ed t. pnelatio weei I Phsiiahn- Puplai- divde by tom-e of.t heoian physP.Pi-t. d . n svuLotdenase dia oe Ifa nveeo lensi..d2 l-I -f-.t. Il prolttn eetseina P Ire Peusthe dLIndd,LP.. Op neby ar L nf .racThindEis.~'l .i. Mi l...i.Il-1 d6 dI Nsald an ldfemale 6165 grdut 70eas peonds sot7 sag, end theteesot ures_ -24 - ANNEX I Page 4 of 5 pages Population 147.4 million (mid-1980) GNP per Capita: US$365 (1979) INDONESIA - ECONOMIC INDICATORS Amount Annual growth rate (Z) (million US$ at (at constant 1973 prices) current prices) Actual _ Projected Indicator 1979 1975 1976 1977 1978 1979 1980 1981 1982 1983 1984 1985 NATIONAL ACCOUNTS Gross domestic product /a 49,211 5.0 6.9 8.8 6.8 4.9 7.1 7.2 7.3 7.3 7.4 7.4 Agriculture 14,678 0.0 4.7 1.3 5.2 2.2 3.5 3.5 3.5 3.5 3.5 3.5 Industry 16,003 5.6 11.1 14.2 5.9 5.5 9.0 9.0 9.0 9.0 9.0 9.0 Services 18.531 10.1 5.9 12.0 8.9 6.9 8.5 8.5 8.5 8.5 8.5 8.5 Consumption 34,686 6.9 6.4 7.9 8.5 5.8 12.4 8.7 7.8 8.1 7.6 6.8 Gross investment 11,103 14.6 6.0 16.0 15.0 5.6 12.0 12.0 12.0 12.0 12.0 12.0 Exports of GNFS 14,788 -9.7 12.5 22.4 0.1 8.9 -2.8 5.6 8.7 9.1 0.0 2.1 Imports of GNFS 11,366 7.9 8.1 22.2 15.6 10.6 10.1 13.1 14.6 15.4 2.6 5.6 Gross national savings 12,400 -19.7 12.0 33.3 -2.1 43.3 19.3 7.2 9.6 9.0 7.4 12.3 PRICES GDP deflator (1973 - 100) 166 190 214 232 309 368 423 473 519 569 621 Exchange rate 415 415 415 442 623 625 625 625 625 625 625 Share of GDP at market prices (%) Average annual increase (%) (at current prices) /b (at constant 1973 prices) 1960 1970 1975 1980 1985 1990 1960-70 1970-75 1975-80 1980-85 1985-90 Gross domestic product 100 100 100 100 100 100 3.9 8.4 6.9 7.3 8.2 Agriculture 54 47 32 29 24 19 2.7 4.1 3.4 3.5 3.5 Industry 14 18 34 33 36 41 5.2 12.0 9.1 9.0 11.2 Services 32 35 35 38 40 40 4.8 9.7 8.4 8.5 8.0 Consumption 91 89 79 74 76 77 4.1 8.4 8.3 7.7 8.7 Gross investment 8 14 20 24 29 3i 4.8 18.3 10.8 12.0 10.0 Exports of GNFS 13 13 23 33 29 23 3.6 9.2 8.7 5.3 3.3 Imports of GNFS -13 -16 -22 -30 -34 -32 3.2 22.1 14.0 10.0 6.8 Gross national savings 8 9 17 24 25 22 6.1 23.1 19.3 9.5 5.9 As % of GDP 1960 1970 1975 1979 PUBLIC FINANCE /c Current revenues 11.7 10.1 10.5 20.6 Current expenditures 14.0 8.4 9.3 12.5 Surplus (+) or deficit (-) -2.3 +1.6 +7.1 +8.1 Capital expenditure n.a. 5.0 10.7 12.4 Foreign financing 0.2 3.5 3.7 4.3 1960-70 1970-75 1975-80 1980-85 1985-90 OTHER INDICATORS Annual GNP growth rate (X) 4.5 7.6 6.3 7.7 8.1 Annual GNP per capita growth rate (%) 2.4 5.1 3.9 5.3 5.7 Annual energy consumption growth rate (%) 2.9 16.0 15.0 11.0 10.7 ICOR 2.2 2.2 3.4 3.5 3.7 Marginal savings rate 0.30 0.48 0.68 0.36 0.24 Import elasticity 1.2 2.8 0.7 1.4 0.8 /a At market prices. 7r; Projected years at constant prices. Owing to favorable terms of trade developments the resource gap's share of GDP at current prices is significantly less than at constant prices. /c Central Government only, on an April-to-March fiscal year basis. East Asia and Pacific Programs August 11, 1981 ANNEX I -25- Page 5 of 5 pages Population 147.4 million (mid-1980) GNP per Capita: USS365 (1979) INDONESIA - BALANCE OF PAYMENTS, EXTERNAL CAPITAL AND DEBT (Millions US$ at current prices) Actual Projected Indicator 1975 1976 1977 1978 1979 1980 1981 1982 1983 1985 1990 BALANCE OF PAYMENTS /a Exports of goods and services 7,425 9,384 11,056 11,650 17,797 23,320 27,624 33,600 40,645 49,391 79,726 Of which: Merchandise f.o.b. 7,283 9,213 10,861 11,353 17,488 22,414 26,375 31,967 38,555 46,430 75,623 Imports of goods and services -8,279 -10,186 -11,746 -12,785 -15,813 -20,407 -24,862 -30,398 -37,365 -46,967 -88,148 Of which: Merchandise c.i.f. -7,362 -8,807 -10,150 -10,907 -13,579 -17,569 -21,769 -27,028 -33,573 -42,230 -79,790 Net transfers 75 61 66 46 52 76 100 50 50 50 50 Cuirrent account balance -779 -741 -624 -1,109 2,046 2,989 2,862 3,252 3,329 2,473 -8,372 Private direct investment 454 287 285 271 217 170 170 200 250 300 500 MLT Loans (net) /b 1,800 1,895 1,131 660 604 1,768 1,788 1,857 1,579 1,273 3_316 Official - source (net) 514 836 752 771 515 1,128 1,644 1,949 1,912 1,646 947 Private - source (net) 1,287 1,059 379 -110 89 640 144 -92 -333 -373 2,391 Other capital -1,839 -442 -140 888 -1,075 -2,417 -2,204 -1,511 -1,267 -738 1,368 Change in reserves 364 -1,001 -651 -708 -1,690 -2,510 -2,616 -3,798 -3,892 -3,308 3,188 Net official reserves 556 1,557 2,208 2,916 4,606 7,116 9,732 13,530 17,422 23,981 25,991 Reserves as months imports 0.8 1.8 2.3 2.7 3.5 4.2 4.7 5.3 5.6 6.1 3.5 Memorandum Items Net exports of goods and services of the oil sector 3,138 3,710 4,445 4,010 6,974 10,577 12,295 12,466 16,523 20,481 27,029 Net foreign assets of the banking system 556 1,557 2,623 3,372 6,906 11,078 15,900 21,297 26,489 35,209 35,885 Total reserves /c as months imports 0.8 1.8 2.7 3.2 5.2 6.5 7.7 8.4 8.5 9.0 4.9 EXTERNAL CAPITAL AND DEBT /b Gross Disbursements 2,152 2,332 1,956 1,641 1,945 2,758 Concessional Loans 503 488 442 494 445 968 DAC 378 365 354 429 405 830 OPEC - - 27 29 5 22 IDA 107 99 49 29 30 56 Other 18 23 12 6 6 59 Nonconcessional Loans 1,649 1,844 _1,514 1148 1,501 1,790 Official export credits 15 267 221 305 88 111 IBRD 57 157 191 168 199 355 Other multilateral 3 11 16 12 46 100 Private - source 1,574 1,409 1,086 663 1,168 1,223 External Debt (fixed-term) Debt outstanding & disbursed /d 8,014 10,018 11,671 13,128 13,326 15,04n Official - source 5,006 5,913 7,077 8,434 8,512 9,657 Private - source 3,008 4,105 4,594 4,694 4,814 5,383 Undisbursed debt 3,703 4,533 4,481 5,832 7,514 8,029 Debt Service Total service payments 517 775 1,266 1,463 2,107 1,804 Interest 165 318 441 485 772 815 Payments as % exports of goods & services /e 7.0 8.0 11.5 12.6 11.8 7.7 Average Interest Rate on New Loans (7) 8.3 7.5 6.3 7.3 6.6 8.8 Official - source 6.5 7.0 5.5 4.7 4.9 5.5 Private - source 9.3 8.1 8.6 10.8 8.9 13.5 Average Maturity of New Loans (Years) 12.7 14.9 20.5 21.2 19.9 18.1 Official - source 21.3 20.2 23.9 30.1 25.7 23.5 Private - source 8.1 8.3 10.4 9.3 11.4 10.3 As % of debt outstanding at end of 1979 Maturity structure of debt outstanding Maturities due within 5 years 30.2 Maturities due within 10 years 64.6 Interest structure of debt outstanding Interest duie within first year 4.0 /a On an April-to-March fiscal year basis. /b Excludes private nonguaranteed loans. /c Includes foreign assets of deposit money banks in addition to official reserves. /d At end of period. 7-e Oil exports treated on gross basis. East Asia and Pacific Programs August 11, 1981 - 26 - ANNEX II Page 1 of 28 pages THE STATUS OF BANK GROUP OPERATIONS IN INDONESIA A. STATEMENT OF BANK LOANS AND IDA CREDITS (as of July 31, 1981) US$ million Loan/ Amount Credit Fiscal (less cancellations) Number Year Purpose Bank IDA Undisbursed Eight Loans and twenty-nine Credits fully disbursed 426.51 458.43 - 300 1972 Population 13.20 0.63 358 1973 North Sumatra Smallholder Development 5.00 0.78 387 1973 Third Education 13.50 3.51 400 1973 Smallholder and Private Estate Tea 7.80 3.51 428 1974 Pulo Gadung Industrial Estate 16.50 8.74 451 1974 Fourth Technical Assistance 5.00 0.95 479 1974 Bali Tourism 16.00 3.99 480 1974 Fisheries Credit 6.50 0.66 514 1975 Jatiluhur Irrigation Extension 30.00 10.67 785 1978 Small Enterprise Development Project 40.00 10.45 827 1978 Rural Credit 30.00 20.37 869 19I9 Polytechnic 49.00 46.56 898 1979 Fifth Technical Assistance 10.00 9.01 919 1979 Transmigration II 67.00 51.51 946 1980 Yogyakarta Rural Development 12.00 11.34 984 1980 Smallholder Rubber Dev. Project 45.00 42.82 995 1980 Fifteenth Irrigation 45.00 42.03 996 1980 National Agriculture Extension II 42.00 41.64 1014 1980 National Ag. Research Project 30.00 29.95 1049 1975 Five Cities Water Supply 14.50 1.59 1100 1975 Sixth Irrigation 65.00 21.02 1179 1976 Agricultural Research & Extension 21.50 6.81 1197 1976 National Resource Survey & Mapping 13.00 5.49 1236 1976 Fourth Highway 130.00 42.58 1237 1976 Fourth Education 37.00 11.98 1250 1976 Second Shipping 54.00 16.35 1259 1976 Fifth Power 90.00 5.96 1267 1976 National Food Crops Extension 22.00 5.63 1268 1976 Seventh Irrigation 33.00 11.22 1318 1977 Transmigration and Rural Development 30.00 9.64 1336 1977 Second Urban Development 52.50 9.09 1337 1977 Tanjung Priok Port 32.00 12.20 1363 1977 Second PDFCI 15.00 1.48 _ 27 7 ANNEX II Page 2 of 28 pages US$ million Loan/ Amount Credit Fiscal (less cancellations) Number Year Purpose Bank IDA Undisbursed 1365 1977 Sixth Power 116.00 38.89 1373 1977 Nutrition Development 13.00 8.96 1433 1977 Teacher Training-Fifth Education 19.00 12.66 1434 1977 Eighth Irrigation 63.00 44.17 1435 1977 Ninth Irrigation 35.00 15.08 1437 1977 Development Finance Co. (BAPINDO III) 40.00 1.49 1472 1977 Second Population 24.50 15.42 1486 1978 Non-Formal Education 15.00 8.34 1499 1978 Nucleus Estates and Smallholders I 65.00 38.76 1513 1978 Seventh Power 94.00 58.03 1578 1978 Tenth Irrigation 140.00 125.47 1579 1978 Eleventh Irrigation 31.00 24.59 1604 1978 Nucleus Estates and Smallholders II 65.00 62.36 1645 1979 Twelfth Irrigation 77.00 62.39 1653 1979 Third Urban Development 54.00 42.97 1691 1979 Lower Cimanuk Basin Flood Control 50.00 44.33 1692 1979 Second Agricultural Training 42.00 39.38 1696 1979 Fifth Highway 123.20 109.69 1703 1979 Fourth BAPINDO 50.00 30.35 1707 1979 Transmigration II 90.00 90.00 1708 1979 Eighth Power 175.00 154.07 1709 1979 Second Water Supply 36.00 34.31 1751 1980 Nucleus Estates and S'holders III 99.00 84.43 1811 1980 Fourteenth Irrigation 116.00 113.91 1835 1980 Nucleus Estates and S'holders IV 42.00 40.81 1840 1980 Nat. Ag. Research Project 35.00 35.00 1869 1980 Third Population Project 35.00 35.00 1872 1980 Ninth Power Project 253.00 245.16 1898 1981 S'holder Coconut Dev. Project 46.00 46.00 1904 1981 University Development Project 45.00 45.00 1950 1981 Tenth Power Project 250.00 250.00 1958 1981 Swamp Reclamation Project 22.00 22.00 1972 1981 Fourth Urban Development Project 43.00 43.00 2007 1981 Nucleus Estate and Smallholder V 161.00 161.00 2011 1981 Second Small Enterprise Development 106.00 106.00 - 28 - ANNEX II Page 3 of 28 pages US$ million Loan/ Amount Credit Fiscal (less cancellations) Number Year Purpose Bank IDA Undisbursed Total Bank loans and IDA credits 3,729.00 931.80 less cancellations -23.13 -1.62 Total 3,705.87 930.18 of which has been repaid -82.63 -2.65 Total now outstanding 3,623.24 927.53 Amount sold to third party 28.24 Amount repaid by third party -27.21 -1.03 Total now held by Bank and IDA /a 3,622.21 927.53 Total undisbursed 2,134.59 346.03 2,480.62 ja Prior to excnxange adjustment. - 29 - ANNEX II Page 4 of 28 pages B. STATEMENT OF IFC INVESTMENTS (as of July 31, 1981) Fiscal Type of Loan Equity Total year Obligor business ---- (US$ million) ---- 1971 P.T. Semen Cibinong Cement 10.6 2.5 13.1 1971 P.T. Unitex Textiles 2.5 0.8 3.3 1971 P.T. Primatexco Indonesia Textiles 2.0 0.5 2.5 1971 P.T. Kabel Indonesia Cable 2.8 0.4 3.2 1972 P.T. Daralon Textile Manuf. Corp. Textiles 4.5 1.5 6.0 1973 P.T. Jakarta Int. Hotel Tourism 11.0 - 11.0 1973 P.T. Semen Cibinong Cement 5.4 0.7 6.1 1974 P.T. Primatexco Indonesia Textiles 2.0 0.3 2.3 1974 P.T. Monsanto Pan Electronics 0.9 - 0.9 1974 P.T. PDFCI Devel. Fin. Co. - 0.5 0.5 1974 P.T. Kamaltex Textiles 2.4 0.6 3.0 1976 P.T. Semen Cibinong Cement 5.0 1.5 6.5 1976 P.T. Semen Cibinong Cement - 1.1 1.1 1977 P.T. Daralon Textile Manuf. Corp. Textiles 0.4 - 0.4 1977 P.T. Kamaltex Textiles 1.3 0.2 1.5 1979 P.T. Daralon Textiles 0.9 - 0.9 1980 P.T. Papan Sejahtera Capital Market 4.0 1.2 5.2 1980 P.T. Indo American Industries Glass Dinnerware 11.1 0.9 12.0 1980 P.T. Semen Andalas Cement and Indonesia Construction Material 48.0 5.0 53.0 Total gross commitments 114.8 17.7 132.5 Less: sold or repaid and cancelled 73.7 3.4 77.1 Total held by IFC 41.1 14.3 55.4 Undisbursed (including participant's portion) 63.1 0.9 64.0 - 30 - ANNEX II Page 5 of 28 pages C. STATUS OF PROJECTS IN EXECUTION /1 As of September 1, 1981 These notes are arranged by sectors in the following order: Page No. Agriculture Irrigation (514, 1100, 1268, 1434, 1435, 1578, 6-9 1579, 1645, 1691, 1811, 995 and 1958) Other Agriculture Production (358, 400, 480, 1318, 9-13 1707/919, 1499, 1604, 1751, 1835, 984, 1898 and 2007) Agriculture Support Services (1179, 1267, 996 and 1840/1014) 13-14 Rural Development (946) - 14 Agro-Business and Credit (785, 827 and 2011) 15 Education (387, 869, 1237, 1433, 1486, 1692 and 1904) 16-18 Energy (1259, 1365, 1513, 1708, 1872 and 1950) 18-20 Industrial Development and Finance Industrial Estates (428) 21 Development Finance Companies (1363, 1437 and 1703) 21 Population and Nutrition Population (300, 1472 and 1869) 22 Nutrition (1373) 23 Technical Assistance (451, 898 and 1197) 24 Transportation Highways (1236 and 1696) 24-25 Marine Transport (1250) 25 Ports (1337) 26 Tourism (479) 26 Urban Development (1336, 1653 and 1972) 26-27 Water Supply (1049 and 1709) 28 /1 These notes are designed to inform the Executive Directors regarding the progress of projects in execution, and in particular to report any problems which are being encountered and the action being taken to remedy them. They should be read in this sense, and with the understanding that they do not purport to present a balanced evaluation of strengths and weaknesses in project execution. - 31 - ANNEX II Page 6 of 28 pages C. PROJECTS IN EXECUTION AGRICULTURE Irrigation Credit No. 514 Jatiluhur Irrigation Extension: $30 Million Credit of October 3, 1974; Effective Date: January 10, 1975; Closing Date: December 31, 1982 Initial organizational difficulties, extensive changes in the design of project works and delays in awarding civil works contracts are expected to substantially delay project completion by four years. All major contracts for civil works have been awarded, and the last of these is expected to be completed by mid-1984. The total project cost is currently estimated to be about 90% over the appraisal estimate. The credit is expected to be fully disbursed by December 31, 1982, the new closing date. Loan No. 1100 Sixth Irrigation: $65 Million Loan of April 10, 1975; Effective Date: June 20, 1975; Closing Date: June 30, 1982 The project is currently expected to be completed by March 1985, about four years behind the original completion date. This is mainly due to a delay of more than one year in the completion of bidding documents, followed by a delay of about two years due to delayed land acquisition, delayed payments to contractors and the effects of the 1978 Rupiah devaluation. Another year's delay has been added lately by the constant postponement of drainage works in both Rentang and Cerebon subprojects due to overall budget constraints imposed by the GOI on the Directorate General of Water Resources Development annual budget during the last three years. Disbursements are currently about 73% of the appraisal estimate. It is possible that because of the continuing delays in this project that the closing date will have to be postponed. Loan No. 1268 Seventh Irrigation: $33 Million Loan of June 4, 1976; Effective Date: September 21, 1976; Closing Date: December 31, 1981 The main components of the project are tertiary development on an area of 100,000 ha served by irrigation systems rehabilitated under previous credits and the construction of 6,000 ha of a new irrigation system in the Sadang area of South Sulawesi. The construction of tertiaries has progressed well and gained such a momentum that the scope of work was increased to 115,000 ha. About 85,000 ha have been completed and the balance will be completed by the end of 1981. The construction of North Sadang has suffered a delay of about three years due to design revisions and late award of contracts. All of the remaining works of the project will be completed by July 1983. Disbursements are currently 25% behind the appraisal estimates. Loan No. 1434 Eighth Irrigation: $63 Million Loan of June 6, 1977; Effective Date: July 7, 1977; Closing Date: March 31, 1983 The main components of the project are rehabilitation of the Madiun Irrigation System serving an area of about 75,000 ha in Stage I including 30,000 ha of tertiary development, pilot ground water scheme for 2,800 ha in - 32- ANNEX II Page 7 of 28 pages the Madiun-Solo area and the improvement of flood control, drainage and road networks on 5,700 ha of coastal land in the Ciujung subproject. The Madiun Irrigation and pilot ground water scheme components have made satisfactory progress and are expected to be completed by the end of 1983. The Ciujung drainage component has suffered the most delay caused by the late completion of feasibility studies and inaccurate maps and some difficulties with land acquisition. Disbursements are currently about 75% behind the appraisal estimate largely due to initial delays but are expected to improve in 1982 when all of the contracts for the Ciujung drainage component will be under implementation. Loan No. 1435 Ninth Irrigation: $35 Million Loan of June 6, 1977; Effective Date: July 7, 1977; Closing Date: December 31, 1981. The project consists of three components: (a) the Sedeku Irriga- tion and Drainage Subproject; (b) the Sungai Dareh-Sitiung Irrigation Project; and (c) various studies and investigations. Progress on these components is as follows: (a) consequent on GOI's decision not to construct the Jragung Dam, the down river drainage works and designs are being reviewed. Delay in completion is currently estimated to be about three years; (b) all the contracts of the Stage I area are awarded and the project is estimated to be completed by mid-1982, a delay of about one year. Problems of land clearing and land shaping on about 3,000 ha to convert to sawahs (wet rice fields) are unresolved and might delay early benefits. The Stage II area was appraised by the Bank in September 1980 and due to a low economic rate of return it was not recommended for further Bank consideration; and (c) feasibility studies of ten systems have beor completed. Three projects were recommended for Bank assistance under the proposed sixteenth irrigation project, two were financed by KfW and one is proposed to be financed by the Asian Development Bank. Three ongoing projects would be completed fully by GOI financing. Disburse- ments are at about 58% of appraisal estimates. Loan No. 1578 Tenth Irrigation: $140 Million Loan of June 6, 1978; Effective Date: August 16, 1978; Closing Date: December 31, 1984. The project includes: (a) rehabilitation and improvements of about 34,700 ha of Kali Progo irrigation system; (b) improvements of about 19,900 ha of Way Seputih; (c) improvements and expansion of about 63,100 ha of Way Sekampung irrigation projects; (d) studies and detailed designs of two dams associated with (b) and (c) above; (e) studies of Dumoga and Gumbasa irriga- tion projects; and (f) consulting services for the above and also studies of two dams in the Kali Progo project area, extension of irrigation to Bekri, West Rumbia, Way Kandis and Way Ketibung in Lampung Province. The Kali Progo project is behind schedule by 12 months whereas the Way Seuptih and Way Sekampung projects have slipped further and are behind schedule by 24 months. The status of down river works of the latter two irrigation systems, associated with the two dams, was reviewed by the Bank in April/May 1981 and the GOI was informed that the rehabilitation and extension of irrigation systems would only be justified if the two dams are built; alternatively the program under the current project has to be curtailed. Subject to resolving the issue within six months and if there are no slippages, the current - 33 - ANNEX II Page 8 of 28 pages estimated completion is December 1985; a delay of two years. Disbursements are currently 33% of appraisal estimate. Loan No. 1579 Eleventh Irrigation: $31 Million Loan of June 6, 1978; Effective Date: August 16, 1978; Closing Date: December 31, 1983. Due to slow progress the project is currently estimated to be completed in June 1983, a delay of about one year. The Hydrologic Measurement Program has been delayed by about 2-1/2 years due to a setback in the program for procurement of equipment and selection of sites for gauging stations. Studies for a master plan for the development of the Cimanuk River Basin have been completed and a final report has been submitted to the Bank. Detailed designs of flood control works of the Lower Cimanuk, Cipanas and Ciwaringin Rivers have been completed and construction is proceeding under Loan 1691-IND. Due to unfavorable foundation conditions at the dam site and GOI's decision not to construct large dams on Java this component is indefinitely postponed and it is proposed that these funds be utilized for feasibility studies of Glapan Barrage and Tuntang River and upgrading of irrigation systems. Disbursements are about 39% of appraisal estimates. Loan No. 1645 Twelfth Irrigation: $77 Million Loan of December 29, 1978. Effective Date: May 10, 1979; Closing Date: March 31, 1984. The Jatiluhur Tertiary Development on an area of 186,000 ha is proceeding on schedule; construction on 103,731 ha has been completed and the balance of the area would be covered in two fiscal years 81/82 and 82/83. The Cisedane drainage works have been delayed; two small contracts of about $2 million were awarded in January-February 1981, and are about 30-40% completed. Tenders for three major contracts, aggregate $30.4 million, received in March-April 1981, are expected to be awarded in November 1981. Right-of-way acquisition is also behind schedule. This subproject is currently estimated to be completed by March 1985, a delay of two years over appraisal estimate. All studies are expected to be completed by July 1982. Disbursements are about 35% of the appraisal estimates. Loan No. 1691 Lower Cimanuk Basin Flood Control: $51 Million Loan of May 7, 1979; Effective Date: October 16, 1979; Closing Date: March 31, 1984. The main components of the projects are flood protection levees, bank stabilization and river training works on the lower Cimanuk river, widening of the Rambatan Channel and construction of a hydraulic control structure at Bangkir, the Cimanuk river estuary study and the flood control operating and flood forecasting study. Good and satisfactory progress has been made on the civil works and various studies. Civil works are expected to be completed by the end of 1983. Disbursements are currently about 50% behind the appraisal estimate largely due to initial delays and lately due to the late award of contracts caused by the review required by the GOI's procurement committee. _ 34 - ANNEX II Page 9 of 28 pages Loans No. 1811 Fourteenth Irrigation Project: $116 Million Loan of April 3, 1980; Effeative Date: July 3, 1980; Closing Date: January 31, 1986 The main components of the project are construction and rehabilita- tion of drainage and flood protection works on the Serang River to reduce flooding of some 61,000 ha of farm land, rehabilitation of Madiun irrigation systems serving about 65,000 ha area of Stage II and tertiary development serving 120,000 ha in the Pemali Comal and Pekalen Sampean Sub-projects. The project is in the initial stages of mobilization for the Serang River. Works in Madiun area and tertiary development are progressing well ahead of schedule. Consultants contracts are being finalized. Credit No. 995 Fifteenth Irrigation Project: $45 Million Credit of April 3, 1980; Effective Date: July 3, 1980; Closing Date: January 31, 1985 The project includes: (a) the completion of the Kosinggolan irrigation system on about 5,500 ha and construction of the new Toraut irrigation system on about 6,600 ha; (b) catchment protection and a nature reserve on an area of about 100,000 ha; (c) institutional support to the Directorate General of Water Resources Development (DGWRD) through consultancy services and training; (d) strengthening of mapping capabilities; and (e) studies and investigations of four irrigation systems. A contract for the construction of the Toraut headworks and the first two kilometers of the main canal commenced in early 1981 and two major contracts are programmed for award in FY81/82. A start has yet to be made on the nature reserve component by the appointment of personnel and the construction of the headquarters. Consultants for the studies and institutional support of the DGWRD have been appointed. The project is currently about 6-8 months behind schedule. Loan No. 1958 Swamp Reclamation Project: $22 Million Loan of March 31, 1981; Effective Date: July 9, 1981; Closing Date: December 31, 1986. This loan was declared effective on July 9, 1981. The project assists GOI's effort to reclaim and settle swamps by implementing a 9,000 ha swamp reclamation and settlement project at Karang Agung, South Sumatra. In addition to physical works, the project comprises the preparation of future swamp investments, an ecological impact study, an investigation of groundwater for drinking and project monitoring. Other Agriculture Production Projects Credit No. 358 North Sumatra Smallholder Development: $5 Million Credit of February 14, 1973; Effective Date: August 13, 1973; Closing Date: December 31, 1981. The 9,000 ha planting program under the project is now completed. Rubber and oil palm continue to show very satisfactory growth with the 1974/75 plantings of rubber and oil palm coming into production. Control of weeding and general maintenance standards will require close supervision up to 1982/83 when all plantings reach maturity. - 35 - ANNEX II Page 10 of 28 pages Credit No. 400 Smallholder and Private Estate Tea: $7.8 Million Credit of June 22, 1973; Effective Date: November 30, 1973; Closing Date: March 31, 1982 The project provides credit through Bank Rakyat Indonesia (BRI) and extension advice through a Project Management Unit for improvement of Indonesian smallholder and private estate tea. Of 13,200 ha, 60% was to be rehabilitated and 40% replanted. Participants have preferred more costly replanting and the target area has therefore been changed to 10,500 ha, and the proportions reversed. The project is making a substantial contribution to the smallholder tea industry with over 7,000 participants (appraisal forecast 7,700); five private tea estates (four factories) making fair to excellent progress; one of two new major tea factories to be built; and 16,000 smallholders helped by excellent village and research institute training. However, disbursements continue to be behind target due to a combination of early sluggish progress in implementation combined with continued delays that occur between BRI branch disbursements and submission of applications for withdrawal. Credit No. 480 Fisheries Credit: $6.5 Million Credit of June 14, 1974; Effective Date: January 8, 1975; Closing Date: December 31, 1981. Initial delays have put the project about 18 months behind schedule. The marine fishing complex at Ambon is completed, making a promising start with twenty fishing boats operating, ten by GOI s skipjack tuna enterprise and ten by a cooperative; two 100 gross ton catcher/carriers have been ordered and are due to be delivered late 1981. The quality of fishpond lending by Bank Rakyat Indonesia suffered early deficiencies, but is now completed; loan arrears worsened statistically since mid-1980 although they improved slightly in the first quarter of 1981. Coverage is much less than appraisal forecast (31% of farmers, 60% of area) and details not yet available, but inflation and the inability of smaller owners to participate are probably the reasons. The skipjack tuna enterprise has improved markedly following a management change, and catches could improve still further. Although not a profitable enterprise, it is expected to improve in FY81/82. Loan No. 1318 Transmigration and Rural Development: $30 Million Loan of July 21, 1976; Effective Date: March 30, 1977; Closing Date: December 31, 1982 Although the project is still about 2 years behind schedule, it has progressed considerably since July 1980. To date about 4,300 families have been settled in Baturaja, which is 95% of the target. About 200 water supply reservoirs have been built at Baturaja. The pasture development program is well established and 4,800 cattle have been distributed. Rubber development at Baturaja is behind schedule and 1,900 ha need to be planted in 1981/82 to complete the program. The cropping system trials continue to progress satisfactorily. Disbursements have now reached 62% of appraisal estimates. - 36 - ANNEX II Page 11 of 28 pages Loan No. 1707 Transmigration II: $90 Million Loan and $67 Million Credit of (Cr. No. 919) June 1, 1979; Effective Date: October 4, 1979; Closing Date: December 31, 1985 There have been delays in the implementation of the project. Land clearing and road construction are now about six months behind appraisal estimates due to: (a) the rejection of large areas identified for site development in the appraisal report due to unsuitability for the agri- cultural development proposed; (b) weak overall project organization and management; and (c) delays in contractor's and consultant's engagement. More recently, significant numbers of unauthorized settlers have been found in areas presently identified for site development, and the GOI has proposed some changes to design criteria for the large areas already prepared. These matters are being reviewed with GOI but will likely take some time to resolve. Consequently, completion of project works and settlement of families are now expected to lag at least one year behind appraisal estimates. Loan No. 1499 Nucleus Estates and Smallholders I: $65 Million Loan of November 18, 1977; Effective Date: January 12, 1978; Closing Date: June 30, 1982 The nucleus estates have planted about 7,000 ha of rubber for smallholders, constructed about 1,400 settler houses and settled about 850 families. In their own estates, the nucleus estates have rehabilitated 18,400 ha of rubber; planted 7,200 ha of rubber; 3,300 ha of coconuts, and 5,600 ha of oil palm and are about to complete construction of three rubber factories and one palm oil mill. Start-up delays are, however, unlikely to be made up, and the loan closing date may have to be extended at some future date. Loan No. 1604 Nucleus Estate and Smallholders II: $65 Million Loan of July 12, 1978; Effective Date: September 13, 1978; Closing Date: December 31, 1983 After a slow start in 1979 due to labor shortage; budgetary cons- traints and procurement difficulties, good progress was achieved in the last twelve months. Further improvement is expected in project implementation. All major project components are, therefore, expected to be completed as originally planned, except the rubber replanting component in Jambi Province, which has run into unexpected difficulties due to the reluctance of small- holders to participate in the replanting scheme. 37 ANNEX II Page 12 of 28 pages Loan No. 1751 Nucleus Estates and Smallholders III: $99 Million Loan of August 13, 1979; Effective Date: November 12, 1979; Closing Date: December 31, 1986 All implementing agencies have made good progress. Although some components are slightly behind schedule, the overall project is on or slightly ahead of schedule. About 7,500 ha of rubber have been planted, half of which is for smallholders. About 420 recently completed settler houses were fully occupied in April 1981. A PNP Estate being upgraded under the project is to take over responsibility for completing the Alue Iemerah smallholder component under NES I (1499-IND) in 1982 from another PTP which has no estate in that area. Loan No. 1835 Nucleus Estate and Smallholders IV: $42 Million Loan of May 16, 1980: Effective Date: August 11, 1980; Closing Date: December 31, 1986 After an initial delay due to lack of maps the project's small- holder development component is off to a good start and is expected to be on schedule by 1982. The Nucleus Estate and Smallholder V (Loan 2007-IND) start-up component has progressed well and, largely because of this, the FY81/82 development targets are likely to be achieved in the major compo- nent supervised. Other project components are approximately on schedule. Credit No. 984 Smallholder Rubber Development: $45 Million Credit of April 3, 1980; Effective Date: May 23, 1980; Closing Date: March 31, 1986 The project continues to make satisfactory progress, but at a pace somewhat slower than envisaged at appraisal. The shortage of vehicles and suitable access road is impeding project implementation. It is anticipated that the planting program for 1981/82 (about 6,000 ha) will be substantially achieved. Disbursement in FY82 are expected to be on target at US$7 million. Loan No. 1898 Smallholder Coconut Development Project: $46 Million Loan of August 25, 1980; Effective Date: November 25, 1980; Closing Date: June 30, 1986 The project has got off to a satisfactory start in spite of delayed establishment of the project entity and late release of funds. There are no major problems with the project at this stage and the planting and rehabilitation targets set for June 1981 should exceed appraisal estimates by approximately 50%. - 38 ANNEX II Page 13 of 28 pages Loan No. 2007 Nucleus Estate and Smallholder V: $161 Million Loan of June 26, 1981; Not yet Effective; Closing date: June 30, 1988 This loan has not yet been made effective. Agriculture Support Services Loan No. 1179 Agricultural Research and Extension I: $21.5 Million Loan of December 19, 1975; Effective Date: February 23, 1976; Closing Date: December 31, 1982 Overall progress continues. Under the Agency for Agricultural Research and Development, civil works in Pangragajian, Baruajak and Margahayu (all highland vegetable) have been completed, while in Sungei Putih, Sembawa (both rubber) and in Sukamandi (Phase I and II rice and palawija crops) are behind schedule due to shortage of laborers and delay in procurement. Civil works are expected to be completed in Sungei Putih, Sembawa and Sukamandi (Phase I) by July 1981 and in Sukamandi (Phase II) by December 1981. Most of the field and workshop equipment, furniture and vehicles has been received. A contract has been awarded for laboratory equipment and chemicals for Margahayu and bids for the same for Sungei Putib and Sembawa are being evaluated. The fellowship program is continuing satisfactorily. Under the Agency for Agricultural Education, Training and Extension, all equipment, furniture and vehicles have been received and distributed to ten completed agricultural information centers (AICs). Preparation of tender documents for two additional AICs at Aceh and Ambon is completed. Extension materials ;e being produced and distributed from AICs. Disbursements under the project are improving. Loan No. 1267 National Food Crops Extension; $22 Million Loan of June 4, 1976; Effective Date: September 21, 1976; Closing Date: June 30, 1982 The project management unit is functioning at full strength at the senior level, four other positions are part-time staff. Over 90% of field extension workers have been appointed, while appointments of subject-matter specialists have exceeded target. However, there is an imbalance in that appointments in the Other Islands is comparatively lower than in Java. Of the projected civil works program of 64% of the new Rural Extension Centers have been constructed and 80% rehabilitated. The entire program is expected to be completed by December 31, 1981. Procurement of vehicles, equipment and furniture and the training program, both inservices and overseas, are progressing satisfactorily. - 39 - ANNEX II Page 1L4 of 28 pages Credit No. 996 Second National Agricultural Extension: $24 Million Credit of April 3, 1980; Effective Date: July 3, 1980; Closing Date: March 31, 1986 The project is the second phase of the national program for strengthening extension services covering transmigration areas, estate crops, livestock, inland fisheries, soil conservation activities in addition to food crops in 26 provinces. All six Assistant Directors are in position, one Assistant Director, one Divisional Chief, and two Sectional Heads are working on part-time basis, the rest being on full-time basis. 57 new Rural Extension Centers (RECs) have been constructed and 31 renovated; 103 jeeps have been procured against the target of 96 during 1980/81. It is proposed to complete the construction and renovation of all RECs during 1980/81. Adequate provision has been made in the budget for planned civil works (procurement of 64 jeeps and provincial and village equipment package), inservice training of 791 field extension workers, 120 extension subject matter specialists and overseas fellowships during 1981/82. Loan No. 1840 National Agricultural Research: $35 Million Loan and $30 (Cr. No. 1040) Million Credit of May 16, 1980; Effective Date: July 16, 1980; Closing Date: June 30, 1990 The project is the second phase in the strengthening of the overall institutional framework of the Agency for Agricultural Research and Develop- ment for agricultural research in fruits, lowland vegetables, livestock, fisheries, forestry, estate crops other than rubber and industrial crops. A Ministerial decree announcing the appointments of directors for the Central Research Institutes and Research Institutes and Centers already approved by the Minister of Agriculture, became effective in March 1981. The project secretary and one head of office are yet to be appointed. Of civil works at six locations planned for 1980/81, four have been tendered and a contract for one awarded. Civil works at twelve locations have been programmed for 1981/82. Fifty candidates for long term local fellowships have been selected. A consulting firm for technical assistance is expected to be appointed in July 1981. Rural Development Credit No. 946 Yogyakarta Rural Development: $12 Million Credit of August 13, 1979; Effective Date: December 5, 1979; Closing Date: March 31, 1987 Project implementation continues to run behind schedule, but staff development and collection/analysis of basic data have made good progress, and physical construction and field operations within the agricultural component show encouraging advances, despite adverse conditions (protracted nonpayment of project staff salaries because of late release of funds and unavailability of transportation). However, an assurance given by the Provincial Government to bridge any financing gaps for payment of staff salaries, due to belated arrival of project funds, from its own budget, - 40 - ANNEX II Page 15 of 28 pages should put staff remuneration on a more regular schedule. The expeditious procurement of project vehicles, the absence of which is more acutely felt as field operations grew in number and scope, remains a major concern. Project completion is presently expected for mid-1987, implying a delay of about nine months. AGRO-BUSINESS AND CREDIT Credit No. 785 Small Enterprise Development: $40 Million Credit of April 7, 1978; Effective Date: August 17, 1978; Closing Date: December 31, 1984 The project provides financial and technical assistance to strengthen Bank Indonesia-s (BI) small credit programs, KIK/KMKP. Despite start-up difficulties, BI has now established and staffed all project management units. The three field units in Central Java, East Java, and West Sumatra are developing new lending approaches and assisting handling banks in project promotion and preparation. The training and studies components of the project are progressing satisfactorily. On the whole, progress under this project (SEDP I) has been satisfactory. The credit component of the project has been fully disbursed, but the technical assistance component will not be fully disbursed for two years. The undisbursed proceeds of this credit are being used for technical assistance to the Ministry of Industry. The closing date has been pubLponed to enable disbursements for the technical assistance component to be made. Credit No. 827 Rural Credit: $30 Million Credit of June 23, 1978; Effective Date: November 3, 1978; Closing Date: March 31, 1985 This project provides long-term credit to about 40,000 smallholders, primarily for fisheries, perennial crops and livestock, and technical assis- tance to Bank Rakyat Indonesia (BRI) for program development, training in term lending, credit procedures and accounting and management information systems. Due primarily to delays in obtaining consultancy services, the project is about nine months behind schedule. Following extension of the project to cover additional provinces and commodities, it is rapidly catching up. Loan No. 2011 Second Small Enterprise Development: $106 Million Loan of June 26, 1981; Not yet Effective; Closing Date: December 31, 1984 From the three regions covered under SEDP I (Credit 785-IND) this project would be expanded to cover all 27 regions in Indonesia where the Small Investment (KIK)/Small Permanent working Capital Credit (KMKP) program has been in operation since 1974. In addition to credit and technical assistance to the banking system, the project provides for the strengthening of - 41 - ANNEX II Page 16 of 28 pages nonfinancial support services for small scale enterprises (SSEs) by the Ministry of Industry. This is being financed by $1 million from the proceeds of this loan and the undisbursed credit proceeds of SEDP I (Credit 785-IND). EDUCATION Credit No. 387 Third Education: $13.5 Million Credit of June 1, 1973; Effective Date; August 29, 1973; Closing Date: December 31, 1981 This first textbook project is an ambitious undertaking under diffi- cult circumstances. Since the start five years ago, over 150 million books have been printed, 120% of the appraisal target, and about 430,000 teachers have been upgraded, or 23% over the original target of 350,000. About 100 million books have been distributed to schools. Textbook distribution to schools continues to pose problems and quality control of textbooks cannot be maintained by the present number and quality of staff. Printing of Grade 5 texts will start soon and the Project Implementing Unit has been asked to take steps to ensure an adequate supply of paper for production of Grade 6 texts as well as reprinting of other texts. Project costs have increased due to the increased scope of the project and inflation since 1973. Credit No. 869 Polytechnic: $49 Million Credit of December 29, 1978; Effective Date: May 11, 1979; Closing Date: June 30, 1985 This credit is helping to finance: (a) the establishment of a technical Education Development Center (TEDC), six polytechnics and four accountancy development centers (ADCs); (b) related technical assistance and associated studies - as required to meet the project's objectives of: (i) establishing a new system for training engineering technicians; (ii) improving accountancy training; and (iii) strengthening educational planning and management. Implementation of physical components is being initiated somewhat behind appraisal schedule but is progressing well and should be completed by July 1982, well before the closing date. Implementation of technical assistance is progressing on schedule for the TEDC and the polytechnics, but lags about 16 months behind schedule for the ADCs. Five studies financed under the project are also behind schedule, in some instances by as much as 24 months. The total project cost is close to appraisal estimate and disbursements exceed appraisal forecasts. Loan No. 1237 Fourth Education: $37 Million Loan of April 15, 1976; Effective Date: June 17, 1976; Closing Date: December 31, 1982 The loan is helping to finance physical facilities and related technical assistance for: (a) two faculties of technology at existing teaching training colleges (FKITs) and four new centralized workshops for technical - 42 - ANNEX II Page 17 of 28 pages training (TTCs) for the Ministry of Education and Culture (MEC); (b) 17 new vocational training centers (VTCs), an existing instructor training center and 25 mobile training units for the Ministry of Manpower (MOM); and (c) new premises for the National Institute of Administration (LAN), the country's principal civil service training institution. In the MEC subproject construction of all institutions has been completed and all are in use though operating under some difficulties since about half of their equipment needs have still to be received. The MOM and LAN subprojects are progressing about two and a half and three years behind schedule respectively and the Closing Date has consequently been extended by two years. Delays have been occasioned, initially, by slow site acquisition and, subsequently, by belated release of funds and prolonged consideration of claims for the adjustment of contract prices to compensate for the 1978 devaluation of the Rupiah. The underlying cause has been weak management. The total project cost is likely to exceed the appraisal estimate by about 50% in local currency terms but only slightly (perhaps 3%) in terms of US$ equivalent (due to the change in the exchange rate during implementation). The rate of disbursement is improving. Adequate steps are being taken to staff new institutions as they are' commissioned and a national skill standards s-stem is being developed. Loan No. 1433 Teacher Training: $19 Million Loan of June 6, 1977; Effective Date: July 7, 1977; Closing Date: June 30, 1983 The project is now progressing satisfactorily. About 36% of civil works have been completed. Phase I is 95% completed. Phase II is approximately 75% completed. Tendering for the third and final phase has begun and construction is expected to be finished in April 1982. Furniture is being supplied to completed buildings according to schedule. Equipment procurement is about one year behind schedule. The first cycle began in July 1981 and will finish in mid-1982. Four hundred administrators are being trained and will conduct local seminars. Project studies are to be completed mid-1981. While disbursements are currently only 31% of appraisal estimates, it is expected that they will accelerate considerably during the coming months. Despite earlier delays and the low disbursement level, the project is expected to be completed as planned. Loan No. 1486 Non-Formal Education: $15 Million Loan of September 14, 1977; Effective Date: November 4, 1977; Closing Date: June 30, 1983 The project aims at strengthening the Department of Education-s nonformal education programs in seven provinces. Financing would cover civil works to renovate two existing and establish four new provincial centers, instructional equipment and vehicles, in-service training, materials development, a basic learning fund, and related technical assistance. Of the six Balai PENMAS (directorates for out-of-school education) centers, five have been completed. Construction at the remaining two centers is 50% completed; 4 3 ANNEX II Page 18 of 28 pages both centers will be ready by August, 1981. All furniture and equipment have been ordered; 80% is already on site and the rest is due to arrive later this year. About 90% of the staff training program is meeting appraisal targets, production and distribution of pretested learning materials is accelerating. The technical assistance program is on schedule; local staff are gradually replacing foreign consultants. Disbursements will increase substantially this year and are expected to reach 90% of appraisal estimates. Loan No. 1692 Second Agricultural Training: $42 Million Loan of May 7, 1979; Effective Date: July 31, 1979; Closing Date: June 30, 1985 The project constitutes the second phase of GOI's long-term strategy to improve the quality and supply of middle level agricultural manpower. Good progress continues to be made. Although some slippage has developed in the physical implementation, it is not yet serious. Costs are tending to rise. The project also provides technical assistance for the improvement of curricula, education planning and evaluation; this technical assistance has started, and fellowship utilization is up to schedule. Efforts to redress a shortage of teachers outside Java are making steady progress. Through its national schools, the Agency for Agricultural Education, Training and Exten- sion is having significant impact on improving the efficiency of regional and private schools, as planned. Little progress has been made on evaluation, tracer or manpower studies; specialist assistance is expected to stimulate these activities. Loan No. 1904 University Development Project: $45 Million Loan of November 13, 1980; Effective Date: January 22, 1981; Closing Date: December 31, 1986 This Loan was declared effective on January 22, 1981. The project is the first phase of a long-term university development program. Its main objectives are to increase the output of high level manpower in the fields of engineering, science, agriculture, and economics (including business administration and accountancy), improve the quality of university education in these four fields, and strengthen the management of the overall university system. ENERGY Loan No. 1259 Fifth Power: $90 Million Loan of May 20, 1976; Effective Date: September 20, 1976; Closing Date: December 31, 1981 Implementation of the project is proceeding satisfactorily to completion. Disbursement targets for FY81 were substantially (98%) met and the loan is expected to be drawn down within the extended closing date (December 1981), six months later than scheduled at appraisal. Installation of 80% of medium voltage (20 kV) cables and 50% of the 20 kV overhead lines has been completed. This represents satisfactory progress as the scope of _ 44 - ANNEX II Page 19 of 28 pages these items of the project was considerably increased as a result of favorable prices obtained during bidding. Progress on construction of the low voltage networks has been slow (about 40%) but it has been programmed to complete the rest of this work by March 1982. Construction of the project should be substantially completed by mid-1982. Loan No. 1365 Sixth Power: $116 Million Loan of February 4, 1977; Effective Date: June 6, 1977; Closing Date: December 31, 1982 Construction work on the project is reaching its final stage. The slow performance of the electrical and mechanical contractor has delayed progress on construction and slowed down disbursements, as the main expenditure now is on this item of work. Firing of the boiler for Unit 4 has been delayed; steam admission will also be delayed, but it is expected that the unit will be in commercial operation during the latter half of 1981. Unit 5 is expected to be commissioned by end-1981. There are no other problems of significance at the power station. There is concern, however, that the 150 kV ring around Jakarta (not Bank-assisted) will not be strengthened in time to run the power station at its full capacity (700 mW), although the electricity authority (PLN) is making a concerted effort to complete ongoing work on the transmission lines and substations involved. The delay in commissioning of Units 4 and 5 is estimated at about nine months and six months, respectively. Loan No. 1513 Seventh Power: $iu9 Million Loan of February 3, 1978; Effective Date: June 30, 1978; Closing Date: December 31, 1983 All contracts have been awarded at highly competitive costs with a substantial reduction in foreign costs and, therefore, $15 million of the loan has been cancelled. The latest cost estimate update indicates that a further saving will be realized compared to appraisal estimate. Subsequently therefore, the Bank has agreed to the inclusion of the following additional studies in the scope of the project: (a) Sunda Strait submarine cable feasibility; (b) optimization of location of future thermal plants: (c) power sector management information system design; and (d) energy pricing study. Construction work at the site has been delayed by the need to devise a new method of pile driving to avoid soil displacement. This work has now been completed and installation of the main plant resumed. The boiler has been received at site and is under erection. The turbo generator is expected to be received during the latter part of 1981. Although work of the civil works of the substations and associated transmission lines has been delayed, it is progressing satisfactorily. The feasibility study of the Turan coal-fired thermal power station site in East Java has progressed to the point of selection of a site for detailed investigations; these are in progress. Contracts for the additional five studies mentioned above have not been signed, but proposals for (a) and (c) have been received and are being evaluated. _ 45 - ANNEX II Page 20 of 28 pages Loan No. 1708 Eighth Power: $175 Million Loan of June 1, 1979; Effective Date: November 5, 1979; Closing Date: December 31, 1984 The project is now about eight months behind schedule due to (a) slow progress of work by the piling contractor in site improvement; (b) delay in finalizing various critical contracts; and (c) delay in final- izing designs and tender documents for the marine works. The most signifi- cant contributory factor in the delays is the cumbersome procedures for evaluating bids and approval of contracts that have been introduced as a result of Presidential Decrees 10 and 14A (procurement procedures). Also, the GOI's budgetary process makes it difficult for the electricity authority and the project management to have flexibility in the deployment of Rupiah funds. The Bank is continuing to pursue these problems with the GOI. Dis- bursements are much slower than projected. Project cost estimates are now based on available contract and tender prices and the total cost of contracts being financed by the Bank loan amount to $140 million, plus contingencies. Present indications are that there will be a saving of about $20 million in the loan amount. Loan No. 1872 Ninth Power: $253 Million Loan of June 13, 1980; Effective Date: October 24, 1980; Closing Date: September 30, 1985 This project is experiencing delays. However, the commissioning date of the second unit of Suralaya is still not affected. Tenders for EHV lines, substations, transformers and reactors were received in November- December 1980 and as of the last supervision mission in July 1981, were expected to be finalized in October 1981. Commissioning date for the EHV lines and substation is now estimated to be June 1982, which would be ahead of the commissioning of the first Suralaya unit in August 1984, though six months behind the appraisal schedule. Progress in land acquisition is satisfactory, the land for all substations has been purchased. Also, negotiations for the purchase of land for tower locations is in progress. Tenders for control and communications equipment were issued in April 1981. Loan No. 1950 Tenth Power Project: $250 Million Loan of March 6, 1981; Effective Date: April 23, 1981; Closing Date: June 30, 1987 This loan was declared effective on April 23, 1981. The project would utilize the hydroelectric potential of the Citarum River to meet Java's growing demand for economical electricity. - 46 - ANNEX II Page 21 of 28 pages INDUSTRIAL DEVELOPMENT AND FINANCE Industrial Estates Credit No. 428 Pulo Gadung Industrial Estate: $16.5 Million Credit of September 14, 1973; Effective Date: November 13, 1973; Closing Date: December 31, 1982 The Pulo Gadung Industrial Estate is now scheduled for completion in 1982. Of 415 ha of raw land now earmarked for acquisition, 358 ha had been purchased as of mid-1981, 164 ha of developed land reserved for factory use has been sold to 210 firms, with employment currently estimated at around 9,700; at full capacity production employment is expected to be around 23,000 workers. Despite the slow development of the estate resulting in protracted disbursement of the credit, and substantially higher cost than estimated at appraisal, PT JIEP's financial performance has been satisfactory. Some adjustments of its dividend, cost and price policies were nevertheless called for and were recommended to PT JIEP during the last project supervision mission. GOI has agreed to designate 22.5 ha of the Pulo Gadung industrial estate as an Export Processing Zone (EPZ) with PT JIEP as the sole administrator. The closing date of the credit was therefore postponed by two years to December 31, 1982, reallocating the remaining funds for the establishment of the EPZ. However, the loan docu- ments have not yet been amended because the required Presidential Decree and subsequent operating license by the Department of Trade and Cooperatives have not yet been issued. Development Finance Companies Loan No. 1363 Second PDFCi: $15 Million Loan of January 28, 1977; Effectave Date: April 21,1977; Closing Date: December 31,1981 The project is proceeding satisfactorily. PDFCI has deliberately spread Bank funds over as large a number of subprojects as possible to match its resources from Bank Indonesia. The loan is now fully committed and disbursements are expected to be completed by the Closing Date. Loan No. 1437 Third BAPINDO: $40.0 Million Loan of June 6, 1977; Effectave Date: September 23, 1977; Closing Date: September 30, 1981 The project is being implemented satisfactorily. The loan was fully committed by the end of 1979 and $36.1 million was disbursed as of March 31, 1981. The loan is expected to be fully disbursed by the present closing date. Loan No. 1703 Fourth BAPINDO: $50 Million of June 1, 1979; Effective Date: September 25, 1979; Closing Date: September 30, 1983 This project is being implemented satisfactorily. Commitments have increased rapidly since the last supervision mission in May 1980. As of March 31, 1981, 73% of the loan had been committed. Disbursements have also caught up and it is now expected that the loan will be fully committed by September 1981 and fully disbursed by the closing date. - 47 - ANNEX II Page 22 of 28 pages POPULATION AND NUTRITION Population Credit No. 300 Population: $13.2 Million Credit of April 20, 1972; Effective Date: November 2, 1972; Closing Date: December 31, 1981 The project is nearing completion. The family planning program continues to show outstanding performance. Annual targets of new contracep- tive acceptors for the period 1972/73-1980/81 were nearly all exceeded. Current contraceptive users as a proportion of married women of reproductive age increased from 27% in 1979 to 36% in 1981. The birth rate is estimated to have declined from about 44-46 per 1,000 population in 1971 to around 32-34 per 1,000 population in 1980. All the activities financed out of project savings have been completed, except the utilization of two overseas fellowships and the installation of the computer. Two officials of the National Family Planning Coordinating Board have been nominated for the fellowships to undergo training during this year. Installation of the computer is expected to be completed shortly and conversion of existing programs and testing are scheduled to also be completed shortly. All activity connected with the computer should be completed by the end of August 1981. Disbursements are expected to be completed by the scheduled closing date of December 31, 1981. Loan No. 1472 Second Population: $24.5 Million Loan of July 6, 1977; Effective Date: August 4, 1977; Closing Date: April 30, 1983 The implementation of the second population project is proceeding satisfactorily. The construction of all buildings has been completed. The major issues outstanding are (a) expediting the implementation of the contraceptive raw materials study, (b) implementation of the community incentive scheme, and (c) acceleration of the rate of disbursement. Regarding the contraceptive raw materials study, the mission was assured that all obstacles will be overcome and progress should be faster in the coming months. The community incentive scheme has been redesigned and the National Family Planning Coordinating Board (BKKBN) undertook to prepare an operational plan for review. This is expected shortly and we expect implementation to start on schedule early 1981. Progress on these aspects, coupled with timely submission of withdrawal applications, should contribute to the acceleration of the rate of disbursement. The BKKBN is also reviewing the costs of the project in order to determine the extent of savings. We expect to receive the revised costs as well as proposals for utilization of project savings, if any, shortly. - 48 - ANNEX II Page 23 of 28 pages Loan No. 1869 Third Population: $35 Million Loan of June 13, 1980; Effective Date: September 10, 1980; Closing Date: March 31, 1985 This loan was declared effective on September 10, 1980 and a smooth start to project implementation has begun. A Ministerial Decree establishing a steering committee and appointing a project coordinator has been signed. Civil works constitute the largest component of this project and considerable attention is being given to this component so that delays will not occur; the mission recommended that the staff entrusted with the handling of this project be brought to at least the strength of that provided for the second project (Loan 1472-IND). Nutrition Loan No. 1373 Nutrition Development: $13.0 Million Loan of March 14, 1977; Effective Date: March 31, 1977; Closing Date: March 31, 1983 Despite initial difficulties which resulted in an overall delay of about 1-1/2 years, project implementation is being improved and sustained. Due mainly to the devaluation of the Rupiah and revised construction standards, project cost is considerably less than anticipated at appraisal. A partial reallocation of funds between components and categories has thus been proposed. This measure, along with 18 months postponement of the completion date, would allow virtually all appraisal targets to be achieved as well as a modest expansion (beyond those targets) of existing activities of the more successfull components, and would not alter project concept, objectives or content. With regard to present project status, the Center for Research and Development of Nutrition (CRDN) is now operational and a long-term research program is under preparation. Food Technolgy Development Center (FTDC) staff have moved to the new campus. The pilot plant is still unfinished, but should be functioning by the end of 1981. Village food storage is fast becoming an important area for further trials and development. Nutrition Academy enrollment has been increased to 24, with consequential staffing and space requirements. Consultants on the Nutrition Improvement Pilot Project (NIPP) have produced an interim report, reintroducing a positive, promotive program which accords with the views expressed by previous Bank missions. Nutrition Education consultants have submitted two reports on communication and behavioral change; pre-tested materials are ready for reproduction. All NIPP villages will be covered. Arrangements have been made for radio and television airtime. The Nutrition Anemia Pilot Project (NAPP) has continued on schedule and shows favorable returns on investment. No advance has been made in the preparation of a master plan for home garden improvement. The closing date has been post- poned by one year to March 31, 1983. - 49 - ANNEX II Page 24 of 28 pages TECHNICAL ASSISTANCE Credit No. 451 Fourth Technical Assistance: $5 Million Credit of January 2, 1974; Effective Date: February 15, 1974; Closing Date: June 30, 1982 Progress under the project is satisfactory. Credit No. 898 Fifth Technical Assistance: $10 Million Credit of May 7, 1979; Effective Date: September 5, 1979; Closing Date: March 31, 1984 Progress under this project is satisfactory. Loan No. 1197 National Resource Survey and Mapping: $13 Million Loan of February 5, 1976; Effective Date: April 2, 1976; Closing Date: December 31, 1983 The National Coordinating Agency for Surveys and Mapping (BAKOSURTANAL) complex at Cibinong is completed, and most of the cartographic, photographic processing, including color photo processing equipment and printing equipment required to produce maps, is installed. Computer equipment for resource analysis including a topographic data bank and flatbed plotter has been installed. Various resource evaluation activities have been undertaken using these facilities. Recruitment and training of new staff, particularly at junior and middle level has recently been accelerated. The new photography operation financed under the parallel Canadian Project was delayed as a result of which the Bank agreed to extend the project until end of 1983. The photography operation is now expected to start in July 1981 and completed at the end of 1983. TRANSPORTATION Highways Loan No. 1236 Fourth Highway: $130 Million Loan of April 15, 1976; Effective Date: August 13, 1976; Closing Date: December 31, 1982 The project has been under implementation for four and a half years. Because of slow execution, the closing date has been postponed by two years to December 31, 1982. The only component still ongoing is the road betterment program and the related consultancies for works supervision. Other consultancies have been completed satisfactorily, sometimes with substantial delays. Design changes by the Directorate General of Highways (DGH) geared to speeding up construction works were reviewed by the October 1980 supervision mission. Most of the changes were accepted but reinstatement of the original standards in a few specific cases is now being finalized by DGH. According to estimates there is expected to be a surplus of up to $10.5 million in the loan account. Ways in which to use this surplus are under discussion; one option is to increase the volume of road betterment by including new sections in the project. - 50 - ANNEX II Page 25 of 28 pages Loan No. 1696 Fifth Highway: $130 Million Loan of June 1, 1979; Effective Date: August 28, 1979; Closing Date: December 31, 1984 Project implementation, which started nearly two years ago, is substantially behind schedule. The causes for delay are: (a) the ambitious project objectives, which translate into program-type components and numerous consultancies; (b) overcentralization of the Directorate General of Highways (DGH); (c) a shift of senior staff within DGH; and (d) new development guidelines of the GOI under Repelita III emphasizing the spread of investments over a larger number of projects with reduced standards. The latest supervision mission noted a marked improvement in project execution, with all components now actively pushed forward by DGH, and the project should be completed with a total delay of only one year. The road betterment program is well underway. The major issue of reoptimization of road betterment standards is now solved satisfactorily and DGIi should soon send to the Bank the contract amendments legalizing the agreed changes. Tendering for the first batch of bridge replacements should start soon. The Provincial Departments of Public Works programs of support works for 1981 have just been submitted to the Bank following several revisions. $6.8 million of the loan amount has been cancelled due to misprocurement of road maintenance equipment. Marine Transport Loan No. 1250 Second Shipping: $54 Million Loan of May 20, 1976; Effective Date: October 8, 1976; Closing Date: December 31. 1981 The project is part of the first phase of the Government's Inter- Island Fleet Development Program and is designed to modernize, expand and improve the efficiency of the inter-island fleet. Demand for general cargo ships in the Regular Liner Service (RLS) expected at appraisal was slow in materializing due to (i) slow scrapping of obsolete ships with consequent reduced replacement demand; and (ii) effects of the rupiah devaluation on the price of replacement ships. Conditions considerably improved in 1979 and 80% of the loan has now been committed. The project entity, P.T. PANN, is reasonably well managed; the operation and maintenance of its ships is being regularly monitored and no major financial problems exist in its Bank-financed operations. P.T. PELNI, the state-owned shipping line, accounting for about half of the RLS, continues to incur substantial losses. On January 27, 1981, Motor Vessel Tampomas operated by P.T. PELNI caught fire and sank while carrying passengers from Jakarta to Sulawesi. The purchase of this ship was financed in part from the proceeds of this loan. The circumstances of the accident are the subject of an ongoing GOI Court of Inquiry. - 51 - ANNEX II Page 26 of 28 pages Ports Loan No. 1337 Tanjung Priok Port Project: $32 Million Loan of November 4, 1976; Effective Date: March 3, 1977; Closing Date: December 31, 1981 The Government-financed works in Basin III, delayed due to the impact of the 1978 Rupiah devaluation, are completed, and the Basin III civil works finance by the Bank loan, also delayed due to the devaluation, are 85% completed. Civil works financed by the Bank loan in the Regional Harbor, are 62% completed. The work is now three months in arrears and a revised construction schedule is being prepared. These delays will probably postpone overall completion of the project to mid-1981 but it is too early to estimate the full effect of delays on project cost. Several Bank-financed studies which are underway or have been completed, will enable the Government to identify components of a further ports project suitable for Bank financing. TOURISM Credit No. 479 Bali Tourism: $16.0 Million Credit of June 14, 1974; Effective Date: December 4, 1974; Closing Date: June 30, 1982 With the exception of the amenity core and the extension of some utility services, infrastructure at Nusa Dua is complete. The access road to Nusa Dua from the airport and the Denpasar bypass road were completed and opened for traffic in December 1980. The preparation of additional infra- structure improvements and possible participation by the Bali Tourism Deve- lopment Board (BTDC) in hotel investment for Nusa Dua utilizing the uncom- mitted portion of the credit is underway. On the other hand, the Ministry of Transport is proposing to use additional funds from the credit to cover the cost overrun incurred on the already completed access and bypass road component. The allocation of the uncommitted funds to the two agencies is under review by the Government. The market for tourism to Bali has held up well in 1980/81. Hotel occupancies in international standard hotels in Bali exceed 80%. The construction of a first hotel (450 rooms) by Garuda at Nusa Dua is progressing well for completion in December 1982. The negotiations with Club Mediterranee for a holiday village has been finalized and the construction is expected to start in early 1982. URBAN DEVELOPMENT Loan No. 1336 Second Urban Development: $52.5 Million Loan of November 4, 1976; Effective Date: March 28, 1977; Closing Date: December 31, 1981 The project consists of provision of basic infrastructural facilities including footpaths, drainage, water supply and human waste ANNEX II - 52 - Page 27 of 28 pages disposal to about 3,000 ha of densely populated slum areas in Jakarta and 374 ha in Surabaya. Community health workers are to be trained under a pilot program in both cities. Except for small carryover items (filter plant, deep wells and health clinics) and the conduct of a proposed urban transport study for Jakarta under the technical assistance component (Jakarta transport study, Semarang and Surabaya drainage studies), the project progress is essentially complete. Upgrading costs for the program have been within the appraisal estimates. About 3,435 ha of kampungs in Jakarta and 441 ha of kampungs in Surabaya have been covered so far, benefitting a total population of about 1.4 million. About 180 community health workers in Jakarta and 93 in Surabaya have been trained and are working in the improved kampungs. The project is expected to be completed by December 1982. Loan No. 1653 Third Urban Development: $54 Million Loan of January 31, 1979; Effective Date: September 26, 1979; Closing Date: December 31, 1984 The project provides basic infrastructural facilities including roads, footpaths, water supply, and sanitation to impoverished, low-income kampungs (neighborhoods) in the cities of Jakarta (750 ha), Surabaya (580 ha) Ujung Pandang (375 ha), Semerang (310 ha) and Surakarta (170 ha), benefitting a total population of about 2.25 million. A comprehensive solid waste management program is also included in Jakarta and Surabaya, together with a drainage program in Surabaya. About 775 community health workers are to be -Zained in the auove two uities to work in the improved kampungs. The kampung improvement is proceeding satisfactorily in all project cities. The implementation progress of solid waste management and drainage components has improved during this fiscal year (FY80/81) compared to last year. This technical assistance component is proceeding satisfactorily. Loan No. 1972 Fourth Urban Development Project: $43 Million Loan of May 8, 1981; Effective Date: September 9, 1981; Closing Date: September 30, 1986 The loan has not yet been declared effective. The project expands the Bank's assistance to GOI's basic shelter programs evolved in earlier projects and concentrated mainly in Jakarta and the major cities of East Java to nine provincial capital cities spread throughout Indonesia. Basic infra- structure and housing facilities will be provided through slum impovement and sites and services developments on a total of over 2,000 ha benefitting an estimatad 800,000 persons. Improvements to citywide infrastructure deficiencies in main drainage; water supply and solid waste disposal will be studied and implemented in three cities. A national urban mapping program covering 125 cities will be undertaken providing base data for future city planning, land registration and valuation programs. Institutional develop- ment is a prominent feature and technical assistance for management, training and feasibility studies to various urban authorities and agencies will be provided. _ 53 ANNEX II Page 28 of 28 pages WATER SUPPLY Loan No. 1049 Five Cities Water Supply: $14.5 Million Loan of October 31, 1974; Effective Date: May 21, 1975; Closing Date: December 31, 1981 The project is about two and a half years behind schedule. Time was lost because of delays in design work, tender evaluations, awards and contract processing. All equipment supply and all major civil works contracts have been completed or are under execution. Pipelaying is the only remaining major work in progress and is delayed by the slow supply of special fittings. A cost overrun of about 45% is expected. Loan No. 1709 Second Water Supply: $36 Million Loan of June 1, 1979; Effective Date: February 29, 1980; Closing Date: December 31, 1984 The project is 9-12 months behind schedule due to delays in loan effectiveness and in tendering and award of contracts. Most procurement contracts for equipment have been awarded except for the water meter contract. The civil works bidding documents for the construction of water treatment plants were approved during the last supervision mission and were tendered in September 1981. A problem affecting the Directorate of Sanitary Engineering (DSE) in managing the project is its delay in employing management consultants to develop the administrative capacity of the seven beneficiary water enterprises (WEs) and to employ a management specialist for DSE's own organization; both actions have been delayed and DSE's staff is not adequately monitoring the WEs because of inexperience and heavy workload. Additional staff have been employed for this purpose and are being trained. - 54 - ANNEX III Page 1 INDONESIA ELEVENTH POWER PROJECT Supplementary Project Data Sheet Section I: Timetables of Key Events (a) Time taken to prepare the project : One year (b) Project prepared by : SOFRELEC of France and PLN (c) First presented to the Bank : March 1980 (d) Departure of the Appraisal Mission : March 1981 (e) Completion of Negotiations : September 1981 (f) Planned Effectiveness : March 1981 Section II: Special Bank Implementation Actions None. Section III: Special Conditions GOI will: (a) annually review with the Bank PLN's recommended development plan and associated financial forecast and financing plan, and facilitate access by PLN to appropriate sources of finance (para. 46); and (b) ensure that sources of coal for the next base-load coal or multiple-fired thermal units in Java will be identified by June 30, 1982 and that arrangements for mining and transport of coal required will be implemented in time for commissioning of these units (para. 54). - 55 - ANNEX III Page 2 PLN will: (a) as part of its annual planning procedures, institute a ten-year financial forecast based on its proposed development plan, test each proposed development plan for financial feasibility, develop a financing plan covering the last five years of the forecast period and ensure that its recommended development plan and associated financial forecast and financing plan are reviewed by the GOI and the Bank (para. 46). GOI and PLN: (a) to take all necessary steps to construct the Central-East Java EHV line by December 31, 1985 (para. 55). IBRD 12453 R HAILAND li5- 8.1d. A..h INOON ESIA O_ H L PI PUBLIC GENERATING FACILITES :BY AREAS South Cheno 5eo RUI OR NGAPORE A H J Wm pi-q ERA 0 'r c c 6, a n K A L I Al/ A N T A N v VI RM4*N &&A U I A T R A R/4/V 14YA Z mv a v 0 a uio P-4-w JAKARTA a n 5e o A V A ADMA W, VA xiii OAII somo*4 xii A nd, a n C e 0 n 300 400 5w 100 3go 410 "'D 6 'q" 100- iu 110- 135- 140. r- - - - -19rs. gP - ,;- t g . , . icr8RD 15652 , S P w AIA R A ! = X INDONESIA ELEVENTH POWER PROJECT JAVA JABOTABEK TRANSMISSiON AND DISTRIBUTION f,~ - $999919. FKF5594 JAV 54 I Rl~~~~~kvblur>s > 1 j <;g ... _.___ 1rF1^V2 (// PLTSWLF1blLAVAI/nUM8EE9~~~~~~~~~~~~~~~~~~~~~~~~~~F/ P19WIL,F19F'19F9f59 r X _ _. \ t \ I - t * 0 N u86X _ . _ _ i V IL A Y H O X 215T94g W 1 V > A 9 T 5 99~~~~~~~~~~~~~~~~~~~~~~~~~~~~~~~~~~WIL V A O S 95 BA I K 9 F 5 95 55 \ L ~~~~~~~~~~~~~~~~~~~~~~~~~~~~~~~~~~~~Iv _S10qr )AF.19~~~~~~~~~~~~~~~~~ 'F-~~~~~~~~~~~~tA ~ ~ ~ ~ ~ .,FF_. B~ ~-~ o ClvalA KILN < Fp F~9 A V A WEST JAVA \F , CF/VTIAL JAVA F 4 XIV \,, , t5 naa Paqm>T5R8t Pm hr /~~~~~~~~/ FAS'T JAVA F r -9FF F1 A A /I